Advanced Search

Law No. 185 Of 20 October 2016 Concerning Certain Measures Necessary For The Implementation Of Projects Of National Importance In The Field Of Natural Gas

Original Language Title: LEGE nr. 185 din 20 octombrie 2016 privind unele măsuri necesare pentru implementarea proiectelor de importanţă naţională în domeniul gazelor naturale

Subscribe to a Global-Regulation Premium Membership Today!

Key Benefits:

Subscribe Now for only USD$40 per month.
LEGE no. 185 185 of 20 October 2016 on certain measures necessary to implement projects of national importance in the field of natural gas
ISSUER PARLIAMENT
Published in OFFICIAL MONITOR no. 848 848 of 25 October 2016



The Romanian Parliament adopts this law + Chapter I General provisions + Article 1 This law establishes some measures necessary to implement projects of national importance in the field of natural gas. + Article 2 (1) Within the meaning of this law, the following terms have the following meanings: a) the concession agreement-the concession agreement of the buses, installations, equipment and facilities related to the National Gas Transport System and the operating activity of the National Gas Transport System natural; b) the competent authority-the national authority responsible for facilitating and coordinating the authorisation procedure for projects of national importance other than projects of common interest, namely the Ministry of Energy, the national authority responsible for facilitating and coordinating the authorisation procedure for projects of common interest, in accordance with the provisions of the Regulation (EU) 347/2013 of the European Parliament and of the Council of 17 April 2013 on guidelines for trans-European energy infrastructures, repealing Decision no. 1.364/2006/EC and amending the Regulations (EC) No 713/2009 , ((EC) No 714/2009 and ((EC) No 715/2009 ,, suitable Government Decision no. 980/2015 on the organisation and functioning of the Energy c) compensation-allowances and/or compensation due by the initiator of the project in exchange for the establishment and exercise of the rights provided by this law; d) pipeline-upstream supply pipeline, natural gas transmission pipeline located on the territory of Romania, which is the object of the project of national importance, including surface installations and all related facilities electricity supply with air and/or underground assembly, access roads, water supply, sewers and optical fiber; e) the working aisle-the area located on both sides of the axis of the pipe, temporarily used during the performance of the works; f) the exhaustive decision-the decision taken by the competent authority for projects of common interest authorising the construction of the energy infrastructure to carry out projects of common interest; g) the initiator of the project-entity with legal personality initiating a project of national importance in the field of natural gas, within the meaning of this law; h) surface installations-natural gas measuring stations, natural gas-measuring stations, natural gas compression stations, sectioning taps stations, technological nodes, overhead power lines, power stations, etc. transformation for power supply, cathode protection stations, anode sockets, terminals and sockets of potential located on the route of a natural gas transmission pipeline, the breezes from the protective tubes, as well as the like, for whose construction and use the land use is necessary on which they are built, for the duration of their existence and operation; i) reconstitution laws- Law of Land Fund no. 18/1991 , republished, with subsequent amendments and completions, Law no. 1/2000 for the reconstitution of the ownership of agricultural and forestry land, requested according to the provisions Law no. 18/1991 and ale Law no. 169/1997 , as amended and supplemented, Law no. 10/2001 on the legal regime of immovable property improperly taken from March 6, 1945 to December 22, 1989, republished, with subsequent amendments and completions, Law no. 165/2013 on measures to complete the process of restitution, in kind or by equivalent, of buildings improperly taken over during the communist regime in Romania, with subsequent amendments and completions, Law no. 247/2005 on reform in the areas of property and justice, as well as some accompanying measures, with subsequent amendments and completions, Government Emergency Ordinance no. 94/2000 on the restitution of immovable property belonging to religious cults in Romania, republished, with subsequent amendments and completions, Government Emergency Ordinance no. 83/1999 on the return of immovable property belonging to the communities of citizens belonging to national minorities in Romania, republished, as amended, Law no. 112/1995 for the regulation of the legal situation of some buildings with the destination of housing, passed into state property, with subsequent amendments, the Law of gratitude for the victory of the Romanian Revolution of December 1989 and for the labor revolt anticommunist from Brasov in November 1987 no. 341/2004 , as amended and supplemented, and Law no. 44/1994 on war veterans, as well as some rights of invalids and widows of war, republished, with subsequent amendments and completions; j) license of operation-license issued by the National Energy Regulatory Authority in the field of natural gas, according to the provisions Law of electricity and natural gas no. 123/2012 , with subsequent amendments and completions; k) works-construction, realization, development, modernization, rehabilitation, retrofitting, operation, operation, intervention in case of damage, revision or repair and maintenance related to upstream supply pipeline/pipes or natural gas transmission that makes/are subject to projects of national importance in the field of natural gas; l) entitled persons-owners of buildings affected by the construction, development, modernization, rehabilitation, retrofitting, operation, operation, interventions in case of damage, revisions, repairs and maintenance of conducts/pipes which makes/are subject to projects of national importance in the field of natural gas, entitled to receive allowances and/or compensation according to this law; m) projects of national importance in the field of natural gas-natural gas projects declared as being of national importance by Government decision, as well as projects of common interest in the field of natural gas, established by European regulations; by this law, they are considered to be national security and security within the meaning of the provisions of Government Emergency Ordinance no. 57/2007 on the regime of protected natural areas, the conservation of natural habitats, flora and wildlife, approved with amendments and additions by Law no. 49/2011 , with subsequent amendments and completions; n) holders of activities-any person who carries out an activity of any nature, with any title, on/or on buildings affected by the exercise of rights by the initiator of the project, involving the use in any way of these buildings. (2) The definitions in this law shall be duly completed with the definitions set out in the following normative acts: a) Law no. 123/2012 , with subsequent amendments and completions; b) Regulation (EU) No 347/2013 ; c) Law no. 18/1991 , republished, with subsequent amendments and completions. + Article 3 (1) The temporary occupation of forest land public property of the state and administrative-territorial units for the realization of works specific to projects of national importance is made free of charge throughout the existence of pipelines related to projects of national importance in the field of natural gas, by way of derogation from provisions art. 42 42 para. ((1) lit. b) of Law no. 46/2008 -Forest Code, republished, as amended. ((2) By way of derogation from provisions art. 42 42 para. ((1) lit. c) of Law no. 46/2008 , republished, as amended, the temporary occupation of the publicly owned forest land of the state and the administrative-territorial units shall be made without payment of the loss of growth determined by the exploitation of the mass wood before the age of technical exploits. ((3) In carrying out the works related to projects of national importance in the field of natural gas, the rent and the value of the loss of growth determined by the exploitation of the wood mass before the age of the technical exploitation, due temporary occupation of privately owned forest land, shall be established by agreement with the owner of the forest land and shall be recorded or paid as indemnity by the initiator of the project, under the conditions of this laws. (4) The owner's agreement for privately owned forest land, provided for art. 40 40 of Law no. 46/2008 , republished, as amended, shall be concluded by the owner in the form of the document under private signature for the temporary occupation of forest land in the national forest fund and shall be submitted in certified copy for compliance with the original of the project initiator at the competent institution shall issue the temporary occupancy approval. ((5) By way of derogation from provisions art. 40 40 para. ((1) of Law no. 46/2008 , republished, as amended, to the realization of projects of national importance, under the law, the temporary occupation of land from the national forest fund is made without the consent of the owner for forest land, others than those in public property of the state or public property of administrative-territorial units, in a situation where no valid title is presented or the owners are known, as well as in the situation of unopened successions or of unknown successors or if an agreement is not reached with the owner. The agreement of the owner in this case is replenished by the declaration of the initiator of the project of own assumption of responsibility and describing the impossibility of obtaining the owners (6) In the situation referred to in par. ((5), the amounts due for the temporary occupation of the forest land, including the value of the capitalized wood mass, shall be recorded as an allowance in a bank account opened in the name of the initiator of the project and shall be issued later by the provision of the project initiator, under the present law. (7) The temporary occupation of privately owned forest land for which the documents proving the property have not been issued is based on a certificate issued by the local commission for the reconstitution of the property right, approved by the mayor, who confirms this situation. ((8) By way of derogation from provisions art. 37 37 para. ((11) of Law no. 46/2008 , republished, as amended, in order to achieve the objectives of national importance in the field of natural gas at distances less than 50 m from the forest lysis is not necessary to obtain the opinion of the territorial structure of the public authority Central responding to forestry. (9) By way of derogation from provisions art. 7 7 para. ((1) lit. b) of Law no. 50/1991 on the authorization of the execution of construction works, republished, with subsequent amendments and completions, in order to carry out projects of national importance in the field of natural gas, the competent authority the project building permit based on the concession agreement and the operating license. ((10) By way of derogation from art. 40 40 para. ((1) of Law no. 46/2008 , republished, as amended, and from the Methodology on definitive removal, temporary occupation and exchange of land and calculation of monetary obligations, approved by Order of the Minister of Environment, Water and Forestry No. 694/2016 , the approval of the temporary occupation from the national forest fund shall be granted on the basis of a) the request of the initiator of the project for temporary occupation of the land from the national forest fund addressed to the central public authority responsible for forestry; b) technical-justifying memo on the need for temporary occupation of the land from the national forest fund, drawn up by the initiator of the project, containing the presentation of technical details regarding the objective, accompanied by the concession or operating licence; c) the detail plan of the target site; d) the copy of the landscaping map on which the site of the objective is materialized, targeted by the forest detour that ensures the management/forestry services, in the situation in which it exists; e) the technical data-clearing sheet for the temporary occupation of the land and the opinion of the forestry detour; f) the topographic plan executed in the 1970 stereographic projection system with Black Sea quota system 1975, of the area subject to temporary removal from the national forest fund, drawn up by natural or legal persons authorized by The National Agency for Cadastre and Real Estate Advertising and appropriated within 5 days from the request of the forest detour that ensures the administration or the forestry services, as the case may be; g) the documents, in copy, showing the holding, if there is, including the agreement of the holder, on the land requested for temporary occupation from the national forest fund or the declaration provided in par. (5), as the case may be; for proof of possession of land public property of the state shall be presented deeds of property or, in the absence thereof, copies of the plot description, including after the complementary data and the record of works executed, taken from the forestry arrangement in force, targeted by the forest detour or extracted from the centralized inventory of the respective goods, attested by the Government under the law, certified for compliance; h) the environmental agreement or the point of view of the environmental authority, as the case may be, to mention the name of the objective, the site established on the basis of the forestry arrangement and the area, and if the achievement of the objective involves deforestation, shall include the location established on the basis of the forestry arrangement and the clearing surface; i) copy of the payment document of the guarantee for temporary employment; j) the opinion of the head of the specialized territorial structure of the central public authority responsible for forestry, which is issued within 5 working days from the submission of the request. ((11) The competence for the approval of the temporary occupation of land from the national forest fund to achieve the objectives of national importance belongs to the Government, at the proposal of the central public authority responsible for forestry. (12) For projects of national importance in the field of natural gas, the provisions art. 39 39 para. ((6) of Law no. 46/2008 , republished, as amended, shall not apply. + Article 4 ((1) By way of derogation from art. 94 94 and 96 of Law no. 18/1991 , republished, with subsequent amendments and completions, temporary removal of agricultural land located in extravilan, affected by the works defined in art. 2 2 para. ((1) lit. k), is carried out by the effect of this law, based on the Government's decision approving the list of agricultural land located in extravilan that are the subject of projects of national importance in the field of natural gas, without being conditioned by obtaining the opinion/approval of the agricultural bodies with attributions (2) The initiator of the project shall submit to the competent authority the request for the issuance of the authorization to build the pipeline/pipelines accompanied by the list of land provided in par. (1), as well as the technical opinion, as the case may be, for the location of the constructions that are executed in the area of land improvement facilities, issued by the National Land Improvement Agency. (3) The competent authority shall transmit to the Ministry of Agriculture and Rural Development, within 7 days from the date of submission of the documentation provided in par. (2), the list of land areas removed from the agricultural circuit according to par. (1) and files in vector electronic format in the 1970 stereographic projection system. (4) Land entered in the list of land referred to in par. ((1) are temporarily removed from the agricultural circuit for the entire duration of the authorization to build the conducts/pipes, without the need to obtain the prior agreement of the owner of the land. (5) The competent authority has the obligation to play on the agricultural circuit of the land registered in the list provided for in (1), temporarily removed from the agricultural circuit by the effect of this law, in the category of use prior to the removal from the agricultural circuit, within one year from the expiration of the validity of the building permit conducts/pipes, on the basis of a Government decision, which is transmitted to the Ministry of Agriculture and Rural Development according to par. ((3). (6) The temporary removal of the land from the agricultural circuit is carried out by the effect of this law, without the deposit of a guarantee, by derogation from art. 93 93 of Law no. 18/1991 , republished, with subsequent amendments and completions. + Chapter II Land rights, established and recognised in favour of the initiator of the project + Article 5 (1) In the case of construction works related to projects of national importance in the field of natural gas, for the exercise of rights of use and servitude on buildings, the initiator of the project will pay: a) allowances for property owners in exchange for limitations to the right of use as a result of carrying out the works; b) compensation for damages caused to owners of buildings or holders of activities affected by the exercise of the right of servitude, established according to art. 8. (2) In the case of surface installations, for the exercise of the right of use, the initiator of the project shall pay to the owners, starting with the completion date of the works (3) For all works related to projects of national importance in the field of natural gas, the exercise of the right of servitude on buildings affected by works shall be carried out by law, without requiring the obtaining of a prior agreement of owners or other rightholders or activities carried out in relation to buildings that would be affected by the works, provided that the notification procedure is fulfilled. (4) Access to the buildings affected by the execution of the construction works is not conditioned by the payment in advance of the compensation and allowances provided in par. ((1). (5) In the case of rehabilitation, retrofitting, modernization, exploitation, revision or repair and maintenance works related to the pipeline/pipelines that make/are subject to the project of national importance, allowances or compensation provided in par. ((1) are paid or recorded within 30 days from the date of the respective works or interventions. + Article 6 (1) The initiator of the project shall transmit to the entitled persons, at least 10 days before the expected date for access to the affected buildings, a notification regarding the start of the execution of the works, which must include the following: a) the name and identification data of the initiator of the project; b) the enumeration of the operations to be carried out on the property, the conditions and prohibitions that the entitled person and the holders of activities must observe in carrying out the operations; c) indication of the date by which the entitled persons and the holders of activities must issue the property; d) the expected date for carrying out the operations referred to in b); e) the mention of the reservation of the right to replace/modify certain operations and/or to add new operations; f) the mention regarding the obligation of the owners to notify the holders of activities, if they are different from the owners; g) the amount of the allowance or, as the case may be, of the compensation due in connection with the immovable (2) The notification is sent to the owners, who are obliged to inform, in turn, the holders of activities. (3) If the owners are not known/identified, the notification is displayed at the headquarters of the local council in whose territorial area the building is located, in compliance with the deadline of at least 10 days before the expected date for access. (4) Land owners and holders of activities affected by the exercise of the right of use and servitude are obliged, after a period of 10 days from the notification transmitted or displayed, to allow access to carry out the related works projects of national importance in natural gas. (5) By exception to the provisions of par. ((1)-(4), in case of damage, technical accidents, calamities or other exceptional events, for emergency works or interventions, the initiator of the project has the right of immediate access to the buildings. Within 5 days from the date the access was made, the initiator of the project will send a written notice to the owners and holders of affected activities, following that payment or recording of allowances and compensation, as the case may be, shall shall be carried out within 30 days of the date of transmission of this notification. + Article 7 (1) In exercising the rights of use and servitude for the implementation of projects of national importance in the field of natural gas, the initiator of the project: a) will use the building for the execution of works; b) will use the building to ensure the normal functioning of the capacity, including by carrying out the necessary revisions, repairs and interventions; c) will have the right of passage underground and on the surface for the works carried out during the existence of the conducts/pipes, including for the works of site organization, storage of materials and equipment and for the access to the place of its location; d) will obtain the restriction or termination of activities that could endanger persons and property and affect the construction and/or operation of the conducts/pipes, the period for which it ensures compensation under the law; e) will have access to public utilities. (2) In exercising the rights provided in par. ((1) lit. a) for the execution of works related to projects of national importance in the field of natural gas, the initiator of the project can use and strengthen, as the case may be, the existing roads for the execution and operation of the conducts (3) The right of passage underground and on the surface provided in par. ((1) lit. c) includes the right to the installation of any facilities related to the pipeline/pipelines that make/are subject to projects of national importance in the field of natural gas, the right to maintain it in operational state after installation, as well as access to the place of its location/to them for works, according to the legal provisions in force. (4) In order to avoid endangering persons, goods or affecting the activities carried out in the working aisle, the initiator of the project has the right, based on the provisions of par. ((1) lit. d), to obtain the restriction or cessation, to the extent necessary and during the works, of the activities carried out in the vicinity of the respective areas. (5) The rights of use and servitude shall be exercised on the public property land of the state and administrative-territorial units, including the public property land of the state and administrative-territorial units of the fund forest, free of charge. + Article 8 (1) The rights of use and servitude on privately owned buildings shall be constituted for consideration under the conditions of this law. The initiator of the project shall pay or, as appropriate, record: a) monthly allowances for owners of buildings in exchange for limitations to the right of use as a result of carrying out the necessary works for projects of national importance in the field of natural gas; b) compensation for all damages caused to the owners or holders of activities affected by the exercise of rights of use and servitude; c) annual allowances of the owners, in the case of surface installations, for the exercise of the right of use. (2) The monthly allowances due in exchange for the limitation of the use of the buildings shall be established on the basis of the evaluation reports prepared by authorized assessors. (. The annual allowances shall be determined on the basis of the evaluation reports drawn up by approved evaluators. ((4) The amount representing the amount of the allowance established according to ((2) and (3) shall be paid or, respectively, shall be recorded according to art. 13 13 para. ((5). This amount is updated annually with the inflation index, for each building, calculated from the date of payment or the record of allowances, and the positive differences resulting from the update will be paid or recorded respectively. ((5) The compensation due to the owners of the buildings or holders of activities affected by the exercise of the rights of use and servitude shall be established by negotiation in view of the following criteria: a) the area of buildings affected by the works; b) the values for the existing or estimated yields of the affected crops and plantations, including the year/calendar/calendar years in which no seeding or other works may be carried out plantations due to the performance of works, communicated by agricultural bodies with attributions in the field-agricultural chambers, directions for agriculture, National Institute of Statistics or agricultural exchange-, as well as for the facilities and/or facilities affected by the works, with the consideration of financial losses in the case the areas of crops or plantations covered by projects financed by national or Community funds; c) the value of the damage caused by the removal from operation of irrigation facilities, dissecting, drainage and combating the erosion of the soil under the administration/property of the National Agency for Land Improvement/federations of organizations land improvements/land improvement organisations; d) restricted activities during the execution of works. (6) The improvements of any kind to the buildings affected by the works related to projects of national importance in the field of natural gas after the date of receipt or, respectively, the display of the notification provided in art. 6 and until the date of access of the initiator of the project to the relevant buildings are not taken into account when determining the final values of the allowances and/or compensation. (7) The entitled persons may request the conclusion of a convention on the amount of allowances and/or compensation with the submission of the request and the documents provided for in art. 12 12 para. ((1) lit. g) and para. ((3). If neither party requests the conclusion of the convention or if the parties do not conclude the said convention within 30 days from the communication of the request to the initiator of the draft according to art. 13 the amount of allowances and/or compensation is established by the initiator of the project, based on the evaluation report prepared for each administrative-territorial unit, on each category of use of the relevant buildings, with compliance with the conditions laid down in ((2)-(5). (8) Persons entitled dissatisfied with the amount of allowances and/or compensation established according to this article may apply to the courts under the conditions of art. 15 15 and 20. (9) The authorized assessor under the law is selected among the evaluators registered in the National Association of Authorized Evaluators in Romania. (10) The cost of assessing the amount of allowances and/or compensation is borne in all cases directly by the initiator of the project. + Chapter III Prior measures to identify the buildings affected by the construction, namely the existence and operation of the pipeline/pipelines that make/are subject to projects of national importance in the field of natural gas + Article 9 (1) The initiator of the project shall draw up the technical documentation necessary to carry out the works, which must include plans with the site of the work for reception. These plans with the site of the work are carried out according to the legal provisions and include: a) delimitation of the working aisle; b) protection zones and safety zones related to conduct/conductel; c) protection and safety zone of power lines and transformer stations related to surface installations; d) areas with a certain protection regime established by law or documentation of spatial planning or approved urban planning documentation; e) the limits of the affected buildings and their surfaces, for each administrative-territorial unit. The initiator of the project has the obligation to transmit the plan with the site to the territorial cadastre offices and real estate advertising for the reception. (2) The resulting spatial data set must comply with the provisions Regulation (EU) No 1.089/2010 of the Commission of 23 November 2010 implementing the Directive 2007 /2/EC of the European Parliament and of the Council with regard to the interoperability of spatial data sets and services. (3) Within 15 days from the receipt of the documentation related to the construction of the conducts/pipes, the territorial cadastre and real estate advertising office receives the plans with the site of the work and will issue the reception minutes. The initiator of the project will transmit to the mayors, to the prefect's institutions and to the county councils the list of buildings located on the construction corridor, including those related to the power lines of surface installations. (4) The plan including the site of the work, as well as the protection areas, the working aisle and the related safety zones, drawn up according to the provisions of par. (1) for each administrative-territorial unit, as well as the way of calculating allowances and compensation according to art. 8 shall be made public by the initiator of the project by displaying at the premises of the local council in whose territorial area the pipeline is located and remain displayed until the completion of the works, as well as by publishing in a newspaper local and on the website of the initiator of the project or project, as the case may be. In the case of projects of common interest, the public participation procedure will be observed according to Regulation (EU) No 347/2013 . From the date of display at the premises of the local council it is prohibited to issue any opinion, agreement, permit and any authorization regarding the buildings that will be affected by the construction of conducts/pipes, other than those necessary to carry out works. (5) As of the date of display of this information and for the entire duration of operation of the pipeline/pipelines that makes/are subject to projects of national importance in the field of natural gas, any natural or legal person respects the area of protection and safety related to them and restricting the activities carried out in these areas, as established by the normative acts governing the design and execution of upstream and natural gas transmission, adopted by the National Regulatory Authority Energy. (6) The owners, holders with any title of the buildings, as well as the holders of activities are obliged to allow access to the buildings for the performance of topographic measurements, geotechnical studies and any operations necessary for the studies of feasibility, as well as archaeological research. At least 10 days before the date set for access, the initiator of the project will notify them in writing. To the extent that, based on the information provided in art. 12 12 para. (1), the representatives of the initiator of the project cannot identify the addresses of the holders with any title of the buildings concerned and/or the holders of activities, the prior notice is considered carried out by displaying it at the council headquarters local of the administrative-territorial unit in whose territorial area the building is located, in a local newspaper and on the website of the initiator of the project, as well as with the use of the means provided in the concept of public participation for projects of common interest, at least 20 days before the date set for making access to the buildings concerned. (7) The urbanism certificates for the works covered by this law and other necessary opinions and authorizations shall be issued according to art. 22 22 and 24. + Article 10 (1) In order to identify the owners and clarify the legal situation of the buildings affected by the construction of the pipeline/pipelines that make/are subject to projects of national importance in the field of natural gas, the initiator of the request information to local, county or national public authorities and institutions with competence in the process of identification, technical or legal delimitation of the affected buildings. (2) If the owner has not been found at the address communicated under the conditions of par. (1) for the stated purpose, the initiator of the project may request, according to the law, the local community public service of record of persons or, as the case may be, the Directorate for the Records of Persons and the Administration of Database the domicile/residence with which it is included in the National Register of Persons. (3) The authorities and institutions referred to in par. (1) and (2) have the obligation to respond to all requests for the provision of specialized information and assistance, in the performance of their legal duties, within 7 working days from the date of receipt of these requests. + Article 11 (1) Within 20 days from the receipt of site plans/localization of work/conducts/pipes according to art. 9, as well as information on the buildings necessary for the establishment and exercise of rights of use and servitude, all authorities, public institutions and entities at local and county level with attributions in the field have the obligation to transmit, at the request of the initiator of the project, centralized data on the legal situation of the buildings located in the area of competence of each such authority, public institutions and/or entities, including information on: a) the buildings that are subject to the procedures for the establishment or reconstitution of the property right in accordance with the provisions of the reconstitution laws, with the specification of the buildings for which the refund procedures have been completed, for they also indicate the property titles issued, and, respectively, with the specification of the buildings for which the procedure for reconstitution of the property right is in progress, for which the property certificates and/or the minutes of the possession, in so far as these documents have been issued; b) the buildings that are not subject to the procedures for the reconstitution of the property right provided in lett. a); for those buildings in the public or private property of the Romanian state or administrative-territorial units, the holder of the property right and the other real rights shall be stated. ((2) For the purposes of this Article, the authorities, public institutions and entities at local and county level refer to mayors and their subordinate services, organized at the level of administrative-territorial units, institutions prefect, local/county commissions for the establishment of ownership of land, central public administration authorities devolved in the territory, with powers in the field of taxation, as well as any other authorities, institutions Local and/or county competent public and entities. (3) Each territorial office of cadastre and real estate advertising shall transmit to the initiator of the project, on request, within 7 days, the land book extracts. (4) Processing of personal data carried out in order to carry out construction and development works related to projects of national importance in the field of natural gas transport and the exercise of rights of use and servitude is done with respect Law no. 677/2001 for the protection of individuals with regard to the processing of personal data and the free movement of such data, with subsequent amendments and completions. + Article 12 (1) The identification of the owners of the buildings on which the conducts/pipes are to be built/built, as well as the holders of activities affected by its construction and operation/thereof shall be done by the initiator of the project by Consultation: a) land book extracts for information from territorial cadastre offices and real estate advertising; b) the database of property data of the National Agency for Cadastre and Real Estate Advertising; c) information on the property titles and/or the minutes of possession obtained from the commissions for the establishment of ownership of the buildings, in accordance with the provisions Law no. 18/1991 , republished, with subsequent amendments and completions, and of Law no. 1/2000 , with subsequent amendments and completions; d) information on restitution provisions/decisions issued pursuant to Law no. 10/2001 , republished, with subsequent amendments and completions, from the mayors; e) information on measures to complete the process of restitution in kind of buildings improperly taken over during the communist regime in Romania, according to Law no. 165/2013 , with subsequent amendments and completions, respectively from the National Authority for Property Restitution; f) information on the prefect's orders issued in accordance with the provisions Law no. 18/1991 , republished, with subsequent amendments and completions; g) plot plans submitted by the mayors; and h) requests to the initiator of the project, provided in par. ((4). (2) The plot plans obtained according to par. ((1) lit. g) are targeted by the mayors, within 7 days from the submission of the documentation by the initiator of the project. (3) Within 10 days from the date of bringing to the public knowledge of the information provided in art. 9 9 para. (4), any person affected by the project may address requests written to the initiator of the project, which must contain the name and surname of the applicant, the home address, as well as the identification data of the affected buildings, attaching to these and the supporting documents relating to the existence of the title on the buildings that will be affected related to projects of national importance in the field of natural gas, and, as the case may be, documents and information on disputes affecting the building. If the property is registered in the land register, land extracts shall be attached for recent information, not more than 30 days before the date of the address, and if the building was dismantled, the ownership or the property is encumbered by tasks, the identification data of their holders will be presented and supporting documents will be attached. (4) The written requests provided in par. (3), together with the supporting documents, in children legalized or certified according to the law, are submitted by the interested persons to the headquarters of the town hall of the administrative-territorial unit within which the buildings are located. Representatives of the City Hall have the obligation to communicate to the initiator of the project the written requests received, within 5 days from the end of each calendar month. (5) If the allowances and/or compensation relating to the same building are required in the contest or in contradiction by several persons, they shall be recorded in the name of the initiator of the project, at the disposal of all persons, to be divided according to civil law. The establishment of allowances and/or compensation is made in accordance with the provisions of art. 8, and access to the building is made in compliance with art. 6. Respective indemnity and/or indemnity is issued only to holders of the rights proven by final court decisions. Any disputes postpone the payment of allowances and/or compensation, but do not suspend the exercise of rights of use and servitude. (6) If the buildings affected by the works are the subject of a succession, and the successors are known and may present the certificate of heir, the compensation/allowance shall be recorded in an account opened on behalf of the initiator of the project, available to the heirs. + Article 13 (1) If no written request is submitted and/or supporting documents, according to the provisions of art. 12 12 para. (4), and if there is sufficient data to identify the entitled persons, the initiator of the project has the obligation to send, within 10 days from the expiry date of the deadline for submission of the requests provided for in art. 12 12 para. (3), a notification to them, mentioning the amounts proposed for the payment of allowances and/or compensation according to art. 8. The notification also specifies the area in the necessary buildings, and the amounts are recorded in bank accounts opened on behalf of the initiator of the project, at the disposal of entitled persons (2) If there is not sufficient identification data of the entitled persons, the initiator of the project shall display at the premises of the local council in whose territorial area the affected property is located, on the website of the initiator the project or the project, as well as in the local newspapers lists mentioning the amounts proposed for the payment of allowances/compensation according to art. 5, as well as the area in buildings affected by works. (3) When identifying the buildings on the route of the pipeline/pipes that make/are subject to projects of national importance in the field of natural gas, in dispute, information provided by the mayors, the prefect's institutions, as well as and territorial cadastre and real estate advertising offices. (4) The right to request the release of the amounts recorded in accordance with the provisions of this law shall be subject to a limitation period of 5 years. Any amounts recorded and unsolicited by persons entitled to receive allowances/compensation until the expiry of the limitation period remain at the disposal of the initiator of the project. (5) The payment, the record and the release of the individual amounts representing allowances and/or compensation shall be carried out as follows: a) the allowances are paid or, respectively, recorded and issued to the owners of the affected buildings, returning them the obligation to compensate the holders of any other real rights to the buildings; b) the compensation due to the exercise of the rights of use and/or servitude on the buildings by the initiator of the project, established under this law, are paid, respectively recorded and issued to the entitled persons who were prejudiced by exercising the rights set out above; c) in the absence of submitting a written request and/or supporting documents according to par. (1), with reference to damage caused to buildings affected by the construction and operation of the pipeline/pipelines related to projects of national importance in the field of natural gas, it is presumed that the owners of the buildings are those entitled to receive the amounts due by way of compensation, with the obligation to compensate the holders of activities that have actually suffered the damage; d) if the entitled persons are identified and they give their consent to the amount of allowances/compensation established according to art. 8, the initiator of the project either makes the payment of allowances and/or compensation by bank transfer to the accounts of the persons provided above, or records the amounts available to the persons entitled according to the convention concluded with them; e) if, although the entitled persons are identified, they refuse to conclude a convention with the initiator of the project, the amounts related to the allowances/compensation shall be recorded at the disposal of the entitled persons, within 30 days from the date on which they refused the conclusion of the Convention; f) the amounts recorded according to lit. d) and e) are paid to persons entitled on the basis of the presentation of identity documents in the manner requested by the financial institution where these amounts are recorded; g) if the entitled persons in the contest are identified, but contest the amounts related to the indemnity/compensation established according to art. 8, the amounts shall be recorded in an account opened on behalf of the initiator of the project, at the disposal of all entitled persons, and are issued to them at the instruction or request issued by the initiator of the project of financial institutions are open the accounts, within 30 days from the date of signature of the convention with the persons entitled or from the date of communication to the initiator of the project of the final court decision or from the date of receipt by the initiator the draft of a declaration concluded in authentic form, signed by the persons entitled, regarding the acceptance of the amount of allowances/compensation recorded in the accounts by the initiator of the project; h) if the entitled persons cannot be identified or if the buildings are the subject of a dispute known or brought to the attention of the initiator of the project, the amounts of money related to the allowances and/or compensation for the respective buildings are recorded in an account opened in the name of the project initiator i) the amounts provided in lett. h) shall be issued, on the basis of the instruction or request issued by the initiator of the project, to the financial institutions where the accounts are opened, within 30 days from the date on which he took possession of the payment request signed by the persons entitled, to which the supporting documents or final court decisions are annexed by which the quality of the applicant for the person entitled to receive allowances and/or compensation is demonstrated; j) if the buildings are the subject of a dispute that is not known or has not been brought to the attention of the initiator of the project, according to the provisions of this law, the amounts related to the allowances shall be recorded or paid according to a)-h); k) if, until the completion of the dispute referred to in lett. j), the amounts were actually paid, the persons who collected the amounts are to compensate the parties that were designated by the court as rightholders on the buildings according to the law; l) if upon completion of the dispute referred to in lett. j) the amounts are recorded in the accounts, they are issued after the final court decision according to lit. i); m) if the heirs are not known or cannot present a certificate of heir or, respectively, the succession is not open, the compensation shall be recorded in an account opened on behalf of the initiator of the project, on account of the succession; n) the compensation provided in lett. m) is issued at the instruction or request issued by the initiator of the project of financial institutions where the accounts are opened, within 30 days from the date of presentation of the initiator of the project by the heirs of the certificate of the heir or the final judgment proving that quality to them; o) where overlaps are identified, the amounts allocated as an allowance shall be recorded in the name of all owners of the buildings affected by the overlap; p) the amounts provided in lett. o) shall be issued in accordance with the provisions of authentic declarations signed by the owners, in the case of settlement of overlapping amicably, or according to the final court decision rendered in this regard. + Article 14 ((1) By way of derogation from provisions art. 21 21 para. ((5) of Law no. 10/2001 , republished, with subsequent amendments and completions, the existence of any administrative procedures, as the case may be, judicial, generated by this law, does not invalidate the constitution and the valid exercise of the rights of use and servitude in favor of project initiator. Also, the existence of a dispute regarding the property, noted or not in the land book, as well as the lack of agreement of the entitled persons with regard to allowances/compensation does not prevent and invalidate the constitution and the valid exercise of rights of use and servitude in favour of the initiator of the project, in which case the allowances/compensation will be recorded in the name of the person registered as owner in the land register. (2) In application of para. (1), if the property is in the private domain of the state, the amount representing the amount of the allowance and/or compensation shall be recorded in the name of the initiator of the project, at the disposal of the holder and the person who made the notification refund in accordance with the provisions Law no. 10/2001 , republished, with subsequent amendments and completions. + Article 15 (1) The site plan and the list containing the buildings affected by the construction of the pipeline/pipes on each administrative-territorial unit, the identification data, containing the name and surname, respectively the name of the persons on whose account they are recorded or to whom the allowances/compensation established in accordance with this law were paid, or, respectively, the buildings whose owners are not known for which the allowances/compensation were recorded according to art. 13 13 para. ((5) lit. h) shall be displayed through the care of the initiator of the project and of the local councils at the premises of the local councils concerned and on the website of the initiator of the project within 30 days from the completion of the payment procedures or, respectively, from the registration of allowances/compensation for buildings located in the respective administrative-territorial unit. (2) Persons entitled dissatisfied with the amount of the indemnity and/or compensation determined according to art. 5 and 8 and paid or recorded, as the case may be, based on the provisions of this law can be addressed to the courts under the conditions of 20, in accordance with the provisions of this Law. The deadline for submitting these applications is one year after the project initiator's display of the final lists containing the identification of the entitled persons and the amounts paid or recorded as indemnity/indemnity, according to par. (1), under penalty of decay. The exercise of remedies on the amount of the indemnity and/or compensation does not suspend and affect in any way the works, namely the exercise of the rights of use and servitude. (3) In order to determine the amount of the allowance and/or compensation, the values at the time of damage to the buildings related to the projects of national importance in the field of natural gas are taken into account. (4) The establishment and exercise of rights of use and servitude, as well as works on edification, maintenance and/or operation of the pipeline/pipelines or its operation/thereof cannot be suspended or stopped at the request of any person invoking the existence of rights, claims or disputes regarding detention, possession or property of buildings necessary for the implementation of projects of national importance in the field of natural gas. + Article 16 (1) The appearance, after the recording or payment of allowances and/or compensation, respectively previously or after the publication of the list provided for in art. 15 15 para. ((1), of any disputes, claims or claims in relation to the amount of allowances and/or compensation, with the rights or with the title of persons on whose account they are recorded or to whom the allowances have been paid and/or the compensation is not may lead to the suspension, invalidation or postponement of the establishment or the valid exercise of the rights of use and servitude provided for in favour of the initiator of the project. (2) The applicants have the possibility to go against the persons to whom the allowances and/or compensation have been paid or issued, according to the rules of common law. + Article 17 (1) Within 60 days from the entry into force of this Law, the National Agency for Cadastre and Real Estate Advertising and the initiator of the project conclude a protocol aimed at regulating a procedure for the identification of land affected by the establishment and exercise of rights of use and servitude. (2) The services will be provided by the National Agency for Cadastre and Real Estate Advertising and subordinated units, free of charge. + Article 18 (1) The lands included in the national forest fund affected by the works are considered temporarily occupied for the duration of execution and existence of the pipeline/pipelines related to projects of national importance in the field of natural gas. ((2) By way of derogation from provisions art. 39 39 para. ((2) of Law no. 46/2008 , republished, as amended, the approval for the temporary occupation of forest land is issued throughout the duration of execution and existence in the national forest fund of the pipeline/pipelines related to projects of national importance in natural gas field. (3) Public consultation for the issuance of approval for the temporary occupation of forest land shall be done together with the public consultation for environmental impact assessment and shall be deemed effected by the issuance of the environmental agreement or the administrative act of the public environmental protection authority. (4) The initiator of the project shall carry out the operations of temporary occupation of land from the national forest fund, as well as from the agricultural circuit of the buildings necessary for the works provided for in art. 2 2 para. ((1) lit. k), regardless of the holder of the right of ownership, administration or other real rights to them, under the conditions of this law. (5) The indemnity granted to owners for privately owned forest land shall be established by applying the Methodology for the definitive removal, temporary occupation and exchange of land and calculation of the monetary obligations, approved by Order of the Minister of Environment, Water and Forestry No. 694/2016 , privately owned forest land assimilating for the calculation of rent and the value of the loss of growth for the exploitation of wood mass before the age of technical exploitation of forest land public property of the state and public property of administrative-territorial units. (6) Forest District on whose territorial area the forest land areas are obliged to draw up, within 20 calendar days from the date of registration of the request, the technical files for temporary transmission, regardless of the existence or the non-existence of a management or forestry service contract concluded between the owner and the forest detour. + Article 19 The route of conducts/pipelines related to projects of national importance in the field of natural gas, as well as the protection and safety zones related to it/them are included in the urban planning and/or spatial planning plans by care of competent authorities + Chapter IV Procedure for the enforcement of regulated rights by this Law + Article 20 (1) All disputes resulting from the non-compliance with the rights and/or non-performance of the obligations established by this law shall be settled by the court in whose territorial area the building is located, according to this procedure. (2) Applications for appeal shall be adjudicated as a matter of urgency and in particular. ((3) The panel to which the case has been assigned shall verify within two days whether the application for appeal complies with the requirements laid down by law. If the application does not meet these requirements, the applicant shall be notified in writing of the deficiencies, stating that, no later than two days after receipt of the communication, he must complete or amend the application accordingly. (4) The judge, as soon as he finds that the requirements laid down by law for the application for appeal are fulfilled, orders by resolution its communication to the defendant, putting it in mind that it has the obligation to file a days from the communication, under the sanction provided by law, which will be expressly provided for. ((5) The meeting shall be communicated immediately to the complainant, who is obliged to respond to the meeting within 5 days of the communication. The defendant will become aware of the response to the encounter from the case file. (6) Within two days from the submission of the response to the meeting, the judge shall fix by resolution the first trial term, which shall be no more than 10 days from the date of the resolution, ordering the citation of the parties. (7) The claimant may modify his application only until the first period to which it is legally quoted. (8) The court terms granted by the court may not be more than 10 days. The procedure for the citation of the parties shall be deemed to be legally fulfilled if the delivery of the citation is made at least 24 hours before the trial deadline. (9) The decision is enforceable and is subject only to the appeal, within 10 days of communication. (10) The deadline for drafting the judgment is 5 days. ((11) The appeal is adjudicated urgently and in particular. The deadlines set will not exceed 10 days. + Article 21 (1) The obligations established by the decisions provided in art. 20 may be carried out by forced execution. The bailiff, within 24 hours of the registration of the application for forced execution, will request the enforcement court to approve the forced execution. (2) The executing court shall settle the application for the consent of the forced execution of the obligation established by the enforceable title, by closing the date in the council chamber, without citing the parties, no later than 3 days after the registration of the application for Enforceability of forced execution. The delivery may be postponed by no more than 24 hours, and the drafting of the decision shall be made no later than 48 hours after the ruling. (3) The contestation regarding the forced execution itself can be done within 5 days. (4) The parties will be quoted in the short term, and the trial of the appeal is made urgently and in particular. (5) The terms of judgment of the appeal to the enforcement of the court granted by the court may not be more than 10 days. ((6) The pronouncement may be postponed by no more than 24 hours, and the drafting of the decision shall be made no later than 48 hours after the ruling. (7) The decision to settle the appeal referred to in par. (3) is subject only to the call, within 10 days of communication. ((8) The appeal is adjudicated urgently and in particular. (9) During the procedures provided for in art. 20 the exercise of rights and/or the performance of the operations presented in the notification sent by the initiator of the project according to 6. + Chapter V Procedure applicable to works. Issuing of other opinions, permits and authorisations + Article 22 (1) The urbanism certificates shall be issued within 15 days from the date of submission of the application. (2) The opinions, agreements, permits and authorisations provided for in the urban planning certificates, with the exception of the environmental agreement and the water management notice, shall be issued and communicated to the initiator of the project within 15 days from the date of the submission of the application, accompanied by the related documentation, under the conditions (3) The issuance of urbanism certificates, of the building permit and/or of exploitation related to the works shall be carried out in compliance with the provisions of the spatial planning plans and urban planning documentation existing at the date of issue certificates and building permit, without the need to develop and/or approve new plans for spatial planning and/or urban planning. (4) By derogation from the provisions of art. 1 1 para. ((1), art. 4 4, 5 and of the definition "Law of execution of construction works" in Annex no. 2 2 to Law no. 50/1991 , republished, with subsequent amendments and completions, respectively from the provisions of art. 2 2 para. ((9) and (10) and art. 5 5 para. (16) of Government Ordinance no. 43/2000 on the protection of archaeological heritage and the declaration of archaeological sites as areas of national interest, republished, with subsequent amendments and completions, and from the provisions of art. 4 4 para. ((2) and art. 24 24 para. ((1) of Law no. 422/2001 on the protection of historical monuments, republished, with subsequent amendments and completions, as appropriate: a) the building permits related to projects of national importance in the field of natural gas may be requested by the initiator of the project on the basis of the operating license or concession agreement, technical documentation and the average/administrative act issued by the competent authority for environmental protection; b) the authorization of the execution of construction works related to projects of national importance in the field of natural gas is made by the competent authority, in compliance with the legal provisions in the field of construction this law; c) authorization of works involving and abolition in whole or in part of some facilities or constructions for which it is necessary to issue an authorization to abolish it is made by the competent authority in compliance with the legal provisions in the field of construction authorization and of this law; d) the building permit is issued within 15 days from the submission of the request in this regard by the initiator of the project; the initiator of the project has the obligation to submit the complete documentation within 6 months from the issuance; e) the period of validity of the building permits issued for projects of national importance in the field of natural gas is 36 months from the date of issue, provided that the execution of the works is started within 12 months from the date the issuance of the building permit; f) the start of works in the time frame provided for in the building permits determine the extension of the validity of the building permits throughout the execution of the works provided by the authorization; g) in the justified case in which the construction works cannot be started within the period of validity of the building permit, the initiator of the project may request the issuing authority to extend the validity of the authorization by at least 15 days before its expiry, where the extension of the validity of the authorisation is granted for a period of not more than 12 months, with the possibility of its successive extension; h) the county departments for culture issue the necessary opinions for the implementation of natural gas projects; i) for projects of national importance in the field of natural gas, the opinions issued by the county departments of culture are of the type: -opinion of principle, issued as a result of the request of the initiator of the project, accompanied by the technical documentation, theoretical archaeological evaluation, opinion necessary to start the notification procedure, obtaining the environmental agreement and the authorization construction, provided that until the start of the works the initiator of the project will realize the intrusive archaeological diagnosis and preventive archaeological research; -the assent, issued as a result of the request of the initiator of the project, accompanied by the results of the intrusive archaeological diagnosis, ordered by the theoretical evaluation report, and of the archaeological research for the diagnostic sites intrusive; j) the assent provided in lett. i) the 2nd indent is issued in compliance with the proposals of the specialized scientific committees, namely: -formulated by the area commissions of historical monuments, when the opinion refers to the intervention on historical monuments, regardless of the value group, in their protection areas and in protected built areas; -formulated by the National Archaeological Commission, when the opinion refers to intervention in archaeological sites; k) the opinions provided in lett. i) and j) shall be issued within 45 days from the date of submission by the initiator of the project of the complete documentation; l) the initiator of the project assumes the risk of modification of the project after obtaining the environmental agreement and the building permit, as a result of preventive archaeological research; m) in the archaeological sites identified by the intrusive diagnosis, the preventive archaeological research is carried out before the execution of the construction works involving interventions on the soil and subsoil; n) the suspension of the construction works on the area with archaeological heritage evidenced by chance does not lead to the suspension of the o) the area with archaeological heritage highlighted by chance is delimited around the place of chance archaeological discovery depending on the surface of the land actually affected by this discovery, without prejudice to the right to use, to exploit and/or start or continue the construction work for the rest of the land area, which is subject to the building permit issued; p) a simplified procedure for carrying out archaeological research and issuing the necessary authorizations, as well as issuing the certificate of archaeological load discharge shall be elaborated by the Ministry of Culture and approved by order of the Minister, within 30 days from the entry into force of this Law. (5) Certificates of urbanism, approvals, agreements, permits or permits, including building permits related to projects of national importance in the field of natural gas, issued before the entry into force of this Law, are valid until the execution of the works for which they were issued. (6) Urban planning certificates, notices, agreements, permits or permits, including valid building permits, issued for these works after the entry into force of this Law, are valid until the execution of the works for which they were issued, respectively until the issuance of the minutes of final reception of the works on the reception at the end of the works, provided that the execution of the construction works within the deadlines provided in par. ((4) lit. e) and f). (7) The initiator of the project has the right to intervene at any time on the pipeline/pipelines that make/are subject to projects of national importance in the field of natural gas, in order to carry out repair works as a matter of urgency, without the need to obtain in advance the necessary opinions, agreements, permits and authorisations, in order to remedy the defects that endanger the environment, as well as the safety and security of the population/consumers, under the law. The building permit for emergency repair work is immediately issued, according to art. 7 7 para. ((16) of Law no. 50/1991 , republished, with subsequent amendments and completions. + Article 23 (1) By derogation from the provisions of art. 22 22 para. ((5) and (71) and art. 27 27 para. (1) of Government Emergency Ordinance no. 57/2007 on the regime of protected natural areas, the conservation of natural habitats, flora and wildlife, approved with amendments and additions by Law no. 49/2011 , with subsequent amendments and completions, the development of projects of national importance in the field of natural gas is allowed in the areas of integral protection and buffer zones in national and natural parks, respectively for the national importance in the field of natural gas will be made permanent or temporary removal from the agricultural circuit and temporary occupation from the forest fund of land within the natural areas protected of national/international interest. ((. The provisions of this Article shall apply and shall be taken into account by the competent authorities for the protection of the environment with regard to any environmental impact assessment procedures and appropriate assessment procedures, where appropriate, for projects of national importance in the field of natural gas, ongoing on the date of entry into force of this Law. + Article 24 Any opinions, agreements, permits or authorizations issued in favour of third persons, for buildings affected by works related to projects of national importance in the field of natural gas, issued after the date of reception by the authorities local public administration of the documentation provided in art. 9 9 para. (3), transmitted to the territorial office of cadastre and real estate advertising, are void of law. + Article 25 By way of derogation from provisions Government Emergency Ordinance no. 19/2006 on the use of the Black Sea beach and control of the activities carried out on the beach, approved with amendments and additions by Law no. 274/2006 ,, as amended and supplemented, the Government Emergency Ordinance no. 202/2002 on integrated management of the coastal zone, approved with amendments and additions by Law no. 280/2003 ,, as amended, and the Law no. 597/2001 on some measures to protect and authorise construction in the coastal area of the Black Sea with subsequent amendments and completions, authorization, construction, execution and operation of pipelines carrying natural gas from deposits located off the Black Sea, up to the pipeline/pipelines of projects of national importance or, as the case may be, to other pipelines that are subject to the projects contained in the plans for the development of the National Natural Gas Transport System are allowed in the coastal area of the Black Sea, including in the area of beaches, by undercrossing, in accordance with a special procedure for this purpose, elaborated by the Ministry of Regional Development and Public Administration, within 90 days of the entry into force of this Law. + Article 26 If a third-party natural/legal person requests the issuance of the urbanism certificate, notices, agreements, permits or authorizations required for the purpose of execution of construction works, as well as the conduct of other types of activities and/or interventions on land located in the working aisle or located in the protection and/or safety zones, the central or local public administration authorities, empowered under the law, have the obligation to establish the necessary opinions, which the applicant must obtain from the initiator of the project. + Chapter VI Final provisions + Article 27 (1) The competent authority for projects of common interest will take steps, in order to comply with the deadlines for the issuance of authorizations/approvals/agreements established by this law in the case of projects of common interest. (2) The provisions of this Law shall be duly completed with the provisions of the Civil Code and the Code of Civil Procedure and those of the Law no. 123/2012 , with subsequent amendments and completions, insofar as they are not contrary to this law. (3) In situations where projects of national importance in the field of natural gas interfere with other transport infrastructures of public interest and/or their safety and/or protection zones, established by law, with reference including the buildings related to these infrastructures, the special laws and framework agreements concluded between the initiator of the project and the infrastructure managers. This law was adopted by the Romanian Parliament, in compliance with the provisions of art. 75 75 and art. 76 76 para. (1) of the Romanian Constitution, republished.
CHAMBER OF DEPUTIES PRESIDENT
FLORIN IORDACHE
SENATE PRESIDENT
CĂLIN-CONSTANTIN-ANTON
POPESCU-TARICEANU Bucharest, October 20, 2016. No. 185. -----