Advanced Search

On Amendments To The Federal Law On Participation In Share Participation Construction Of Apartment Buildings And Other Real Estate And On Amendments To Certain Legislative Acts Of The Russian Federation "and On Amendments To Some Zakonodatel'ny

Original Language Title: О внесении изменений в Федеральный закон "Об участии в долевом строительстве многоквартирных домов и иных объектов недвижимости и о внесении изменений в некоторые законодательные акты Российской Федерации" и о внесении изменений в отдельные законодательны

Subscribe to a Global-Regulation Premium Membership Today!

Key Benefits:

Subscribe Now for only USD$40 per month.
RUSSIAN FEDERATION FEDERAL LAW amending the Federal Act on sharing real estate and other buildings changes in some legislative acts of the Russian Federation " and amendments to selected legislative acts of the Russian Federation adopted by the State Duma on June 30, 2006 On 7 July 2006, the Federation Council of the Federation (In the wording of Federal Law of 30.11.2011) N 362-FZ) Article 1 OF THE PRESIDENT OF THE RUSSIAN FEDERATION (40) the following changes: 1) in article 1: (a) in Part 1 of the word "ownership of equity objects," should be replaced with " ownership rights to equity ownership and the right of shared ownership Common property in apartment building and (or) other real estate, "; b) Part 2 should read: " 2. In addition to the provisions of paragraph 1 of this article, the use of funds by citizens for the construction (creation) of multi-apartment buildings and (or) other real estate objects by a legal entity with the acceptance of obligations after execution of which a citizen has the right to own a dwelling in a building (created) of a multi-apartment building, is permitted in cases where the money of the citizens is attracted by issuing by the issuer of the property or on the right of the lease Land and obtained permits for Construction of a special type of housing certificate on this land plot, special form bonds-housing certificates, which enshrinte the right of their owners to receive residential premises from the issuer in accordance with the laws of the Russian Federation on securities and the housing and housing cooperatives, in accordance with the federal laws regulating the activities of such cooperatives. "; in), supplement Part 3 reading: " 3. This Federal Act does not apply to the relations of legal persons and (or) individual entrepreneurs connected with the investment activities for the construction (creation) of real estate objects (including multi-apartment buildings) (...) (...) These relations are regulated by the Civil Code of the Russian Federation and the legislation of the Russian Federation on investment activities. Transfer of rights to citizens by assignment to contracts entered into by legal entities and (or) individual entrepreneurs and related to investment activities in the construction (establishment) of blocks of flats and after execution that citizens have the right to own a dwelling in a building (created) of a multi-apartment building are not allowed. "; (2) in article 2: (a), paragraph 1, amend to read: " 1) Developers- legal entity, irrespective of its legal and organizational form ownership or lease rights of a plot of land and the funds of the parties involved in the construction, in accordance with this Federal Law for the construction (creation) on this land plot of apartment buildings and (or) other objects of real estate, other than those of a production facility, on the basis of the building permit obtained; "; b), paragraph 2, after the word" premises, "add" common property in the apartment house and (or) other property, ", to be replaced by the word" subject " "to be", replace "incoming" with "incoming"; 3) in article 3: (a) Part 1, as follows: " 1. The developer has the right to attract funds of the parties involved in the construction of the apartment building (creation) of the apartment building and (or) other real estate only after receiving the building permits in accordance with the established procedure. Publication, publication and (or) submission of a project declaration in accordance with this Federal Act and the State registration by the developer of ownership of the land provided for construction (creation) of a multi-apartment building and (or) other real estate (b) Part 2 of the word "may arise" in Part 3, in Part 3, in Part 3, the word "may arise" should be replaced by the word "arising"; (4) in article 5: (a) in Part 4, the words "by the developer of the requirement of the avoidance of a contract" should be replaced by the words " unilateral refusal of the developer to perform the contract in the manner provided for in article 9 of this Federal Law "; b) in Part 5 of the word" by the developer of the requirement of the termination of the contract "to be replaced by the words" the unilateral refusal of the developer to perform the contract in the manner provided for in article 9 of this Federal Law "; in Part 6 of the word" one. "to replace the words" one three hundred "; 5) in article 6: (a) Part 1, as follows: " 1. The developer is obliged to transfer the equity construction to the contributor at no later than the period stipulated by the agreement and must be common to the parties of the equity construction, to which the developer is obliged to transfer the objects of the equity construction Construction of a multi-apartment house and (or) other real estate unit or section of an apartment block which has a separate entrance with access to the public domain, except in the case of Part 3 of this article. "; b) in Part 2 of the word" one In addition to the words "one three hundred", add the following sentence: "If the participant of the construction is a citizen, the amount of the penalty provided for in this part (s) shall be paid by the developer in a double size."; (6) In article 7: (a) in Part 1, the words "or in the absence or otherwise of the terms of such a treaty" by the word "contract"; (b), first part 2, after the words "the terms of the contract", add the words " and (or) as referred to in Part 1 of this Article of the Mandatory Requirements "; in) Part 3 After the words "equity construction", add the words "or failure to address the identified gaps in the designated equity construction contributor"; ) be supplemented with Part 7, which read: " 7. The developer is not responsible for the defects (defects) of the fractional-construction object found within the warranty period if it proves that they occurred as a result of normal wear and tear of the co-construction site or parts thereof, Violation of the requirements of technical regulations, town planning regulations, as well as other mandatory requirements for the process of its operation, or due to improper repair carried out by the participant in the equity construction or engaged third persons. "; 7) in article 8: a) Part 3 of the word "within two months, but" delete, to be supplemented with the following sentence: "No early fulfilment by the developer of the obligation to transfer the ownership of the equity construction is permitted, unless otherwise stipulated by the contract."; b) Part 4 should be redrafted to read: " 4. A developer of at least one month prior to the date set by the contract for the transfer of the equity construction or if the contract provides for the start of the transfer and the adoption of the object of the equity construction, at least 14 The working days before the start of the transfer and acceptance are obliged to send a message to the participant of the construction on completion of the construction (creation) of the apartment building and (or) other real estate in accordance with the contract and on the readiness of the share-building object to be transferred, and to warn the participant The need for equity construction and the consequences of failure to act on the part of the equity participant referred to in Part 6 of this article. The message should be sent by mail by registered mail with an inventory of the attachment and a notice of the handing over of the share building to the address or to the participant of the equity construction in person under the receipt. At the same time, the period of commencement of the transfer and the acceptance of the object of the equity construction cannot be fixed earlier than fourteen days and later than one month prior to the contract stipulated by the developer of the equity construction project participant equity construction. A participant of the equity construction, who received a message from the developer to complete the construction (s) of the apartment building and (or) other real estate in accordance with the contract and the readiness of the share-building object to transfer, is obliged (c) Proceed to its adoption within the time limit provided by the treaty, or, if such time is not set, within seven working days of the receipt of the communication. "; in) to be supplemented by Part 6 reading: " 6. Unless otherwise stipulated by the agreement, when the participant of the equity construction is evading the construction of the equity construction to the specified part 4 of this article, or when the participant of the equity construction is refused from the adoption of the share Construction (with the exception of the case referred to in part 5 of this article) a developer at the end of two months from the date stipulated by the contract for the transfer of the equity construction to the construction participant, is entitled to unilateral act or other instrument of transfer of the share building facility (for exception to the early transfer of the equity construction referred to in part 3 of this article). At the same time, the risk of accidental death of the co-construction site is recognized as a risk to the participant of the equity construction from the date of the completion of the unilateral act or other document on the transfer of the equity construction. Such measures may only be applied if the developer has information about the receipt by the participant of the construction of the communication in accordance with part 4 of this article or by the operator of the postal service, the registered letter is returned from A communication about the refusal of the participant of the construction or the absence of a participant in the construction at the specified postal address. "; 8) in article 9: (a) the name to be presented in the following editions: " Article 9. Dissolution of the contract "; b), Part 1, as follows: " 1. The participant of the equity construction unilaterally has the right to refuse the performance of the contract in the case of: 1) failure by the developer to fulfill the obligation to transfer the equity construction within the stipulated time period; 2) failure by the developer to comply with article 7, paragraph 2, of this Federal Law; 3) a material breach of the quality requirements of the equity construction; 4) by the developer responsibilities under article 15, paragraph 3, of this Federal the law; 5) in other cases specified by federal law or by the treaty. "; in) to be supplemented by Part 1, paragraph 1, as follows: " 1-1. At the request of the party, the contract may be terminated by a court in the case of: 1) termination or suspension of the construction (s) of the apartment building (s) and (or) other real estate is the construction site, where there is evidence that there is no evidence that the equity construction project will not be handed over to the equity participant; 2) changes to design documents of construction (created) of a multi-apartment house and (or) other real estate, including a significant change in the size of the equity construction; 3) changes in the assignment of common property and (or) Non-residential premises which are part of the apartment building and (or) other real estate; 4) in other cases established by federal law or contract. "; d) Part 2, as follows: " 2. in the event of the termination of a contract on the grounds provided for in Part 1 of this article, within twenty working days of the termination of the contract or in the event of the termination of the contract on the grounds provided for in Part 1-1 of this Article, within ten working days from the date of termination of the contract, it is the duty of returning to the participant of the equity construction the money paid to them against the price of the contract, and also to pay interest on that amount for the use of the said money in the The amount of one three-hundredth of the refinancing rate of the Central Bank of Russia The Federation, acting on the day of performance of the obligation to repay the money paid by the equity participant. The interest is accrued from the date on which the participant of the construction of the money or part of the money is paid to the price of the contract until the day of their return by the developer to the contributor of the equity construction. If the participant of the equity construction is a citizen, the specified interest is paid by the developer in a double size. If, within the prescribed time period, the developer did not apply to the developer for the cash paid by the equity contributor to the price of the contract, and interest on that amount for use by the said money, the developer is obliged to deposit money and interest for the use of the money in the notary's deposit at the location of the developer. What is reported to the equity participant. "; d) supplement Parts 3 to 7 as follows: " 3. If there are grounds for the unilateral refusal of the developer to perform the contract stipulated in article 5, parts 4 and 5 of this Federal Law, the developer is entitled to dissolve the contract no earlier than thirty days after the direction of the contract In writing, the participant of the equity construction, in accordance with the procedure provided for in article 8, paragraph 4, of this Federal Act, warnings of the need to repay the debt in payment of the price of the contract and the consequences of default requirements. Upon failure of the party to do so, and if the developer is informed of the participant's receipt of the equity penalty, the payment of the price of the contract and the consequences Failure to comply with such a requirement or return of the registered letter by the postal operator indicating the failure of the participant of the construction to obtain it, or because of the absence of a contributor to the post office The developer has the right to unilaterally refuse to perform in accordance with Part 4 of this article. 4. In the case of a unilateral waiver by a party to the performance of a treaty, the contract shall be deemed to be terminated from the date on which the other party is notified of the unilateral waiver of the contract. The specified notification must be sent by mail by registered mail attachment. 5. In the case of a unilateral refusal of the developer to perform the contract on the grounds provided for in articles 4 and 5 of this Federal Act, the developer is obliged to return the money paid by the participant of the equity construction to the account. The prices of the contract, within ten working days of its dissolution. If, within the specified period, the developer did not apply to the developer for the money paid by the equity contributor to the contract price, the developer is not later than the day after the expiry of the working day The specified period of time is obliged to deposit these funds in the deposit of the notary in the place of construction of the developer, which is reported to the participant of the equity construction. 6. In the event of a violation by the developer of the term of return of the money or the period of crediting of these funds to the notary, the developer pays the participant of the equity construction the interest on that sum Use of the said moneys in the amount of one hundredth of the refinancing rate of the Central Bank of the Russian Federation acting on the day of the relevant performance of the obligation to return the money paid by the participant equity construction. The interest is accrued from the day following the day of the expiry of the period of return of the money builder to the participant of the equity construction or the period of deposit of these funds in the notary's deposit, until the day of cash return The developer of the share building or the day of deposit of such funds with the notary's deposit. If the participant of the equity construction is a citizen, the specified interest is paid by the developer in a double size. 7. When the property developer is returned, in case of unilateral refusal of the contract, the payment of a claim for payment by the participant of the liquidated damages (penalties) provided by this Federal Law or Treaty shall not be required. is allowed. "; 9) to supplement Article 12-1 as follows: " Article 12-1. How to enforce the Contract Contract 1. The performance of the developer's obligations must be ensured for all contracts entered into for the construction (s) of the apartment building (s) and (or) other real estate on the basis of one building permit, in one of the following ways: 1) bail in accordance with articles 13 to 15 of this Federal Law; 2) surety in accordance with the procedure provided for in Article 15-1 of this Federal Law. 2. In accordance with articles 13 to 15 of this Federal Act, and in accordance with the procedure provided for in article 15-1 of this Federal Act, the following obligations of the builder are enforceable: 1) refund of funds contributed by the participant of the equity construction, in the cases provided for by this Federal Law and/or by contract; 2) the payment to the participant of the equity construction of the money due damages and (or) as liquidated damages (fine, foams) Due to non-default, late performance or other improper performance of the obligation to share the equity construction with the State party under the contract and (or) federal laws money. "; 10) in article 13: (a) the title should read: Article 13. Enforcement of obligations under a contract bond "; b) Part 4 to declare invalid; in) in Part 6: the first paragraph after the word" is allowed "to be supplemented with the words" in the case of security by the developer of the performance of their obligations under the contract by suretyship or "; paragraph 2, in addition to the words", as well as consent to the termination of the right of bail to equity construction in the case provided for in Part 8 of this Article "; g) Part 7 should read: " 7. Following the conclusion of the contract with the first State party, the property referred to in parts 1 to 3 of this article may not be posted on bail without the consent of the parties to the equity construction, except in the case of bail The bank, in order to ensure the repayment of the loan provided by the bank to the developer for the construction (creation) of the apartment building and (or) other real estate, which includes the objects of equity construction, provided that the bank agrees to meet their claims against the foreclosing property in the In accordance with article 15, paragraph 2, of this Federal Act and the consent to the termination of the deposit on the facilities of the equity in the case provided for in Part 8 of this Article. "; " 7-1. In the cases provided for in paragraphs 6 and 7 of this article, the developer is entitled to attract funds of the equity participants not exceeding the sum of the credits received from the banks in the project value specified in the project declaration The construction (creation) of a multi-family house and (or) other real estate object. "; e), Part 8, as follows: " 8. Since signing by the parties of a transfer act or other instrument for the transfer of a facility, the right of deposit arising under this Federal Act, as well as on the basis of a contract with a bank in the stipulated parts 6 and 7 This article does not apply to this part of the construction. "; 11) of article 14, paragraph 3, shall be declared void; 12) in article 15: (a) in Part 6 replace" in Part 6 "with" in Part 6 " and 7 "; b) in Part 2, replace" in Part 6 "with" Parts 6 and 7 "; (in) Parts 3 and 4 are declared invalid; 13) to supplement Article 15-1 as follows: " Article 15 -1. Enforcement of obligations under a contract surety 1. The performance of the developer's obligations under the contract may be ensured by the bank's sponsorship. 2. The guarantee contract is signed prior to the State registration of the contract and should provide for: 1) the joint responsibility of the guarantor before the participant of the equity construction under Part 2 of Article 12-1 of the present The federal law is bound by the obligations of the developer under the contract; (2) the transfer of rights under the contract of sponsorship to the new party in the case of assignment of contract claims; 3) the duration of the guarantee, which should be no less than six months higher than the The agreement of the guarantor for the possible modification of the obligations of the agreement, including the modification of the liability of the participant of the equity construction; 4). Other adverse effects on the guarantor; 5) the obligation of the guarantor to notify the participant of the equity construction in the event of early termination of sponsorship in the manner provided for in Part 3 of this Article. 3. In the event of termination of sponsorship before the expiration of the guarantee provided for in Part 2, paragraph 3, of this article, the guarantor and developer are required to notify the party of the construction at least one month before the date of bail. termination of sponsorship. At the same time, the developer is obliged to conclude another contract of sponsorship within fifteen days from the date of termination of the sponsorship. 4. In the event of a breach by the guarantor of the obligation under Part 3 of this article, it shall be liable to the party to the equity construction under Part 2 of Article 12-1 of this Federal Law. by a contract builder. "; 14) in article 19, paragraph 2, the word" authorized "to replace the word" controlling "with the following sentence:" The developer has the right not to publish in the media and (or) not place in public information and telecommunications networks The project declaration, if the funds involved in the construction of the apartment building (s) and the (or) other real estate are not produced, placed and disseminated, associated with such fundraising. In this case, the developer is required to submit the project declaration to any interested person for consultation. "; 15) in article 20: a) in Part 1: paragraph 1 the name, location and mode of operation of the developer; "; paragraph 3, in addition to the words", which have five and more per cent of the votes in the body of that legal person, with an indication of the name (s) of the legal person-the founder (the participant), the surname, first name, patronymic of the natural person who is a founder member, and the percentage of votes that each such founder has (participant) in the control of that legal person; paragraph 4, in addition to the words ", with a reference to the place finding the specified real estate objects, commissioning dates according to project documentation and actual commissioning dates "; in paragraph 6 of the word" value of own money ", delete; b) In Part 2: paragraph 4 is void; item 5 should be supplemented with the words "(with the exception of the accounting registers)"; in) to be supplemented with Part 3 reading: " 3. The developer shall submit the documents referred to in part 2 of this article, in the originals or in the form of duly certified copies. "; 16) Part 1 of Article 21: a), to supplement paragraph 9-1 as follows: "9-1) on the planned cost of construction (s) of the apartment building and (or) other real estate;"; b) to supplement paragraphs 11 and 12 of the following: " 11) on the means of enforcing the obligations contract; 12) other contracts and transactions on the basis of which attract funds for the construction (s) of the multi-family house and (or) other real estate other than the use of money under the contract. "; 17), article 23 should read as follows: " Article 23. State regulation, control and oversight of the equity construction of apartment buildings houses and (or) other objects of real estate 1. State regulation of the construction of apartment buildings and (or) other objects of real estate is carried out in accordance with this Federal Law by the authorized federal executive authority (hereinafter referred to as the federal law). The competent authority), as well as other federal executive bodies within their competence. 2. Control and supervision of the construction of apartment buildings and (or) other objects of real estate are carried out in accordance with this Federal Law by the authorized body of the executive power of the constituent entity of the Russian Federation, the territory of which the construction is being carried out (hereinafter referred to as the controlling authority). 3. The authorized body is entitled: (Paragraph 6 of paragraph 17 is no more effective-Federal Law of 30.11.2011). N 362-FZ) (2) to issue, within its competence, the legal acts necessary for the implementation of state regulation in the area of the construction of multifamily buildings and (or) other real estate objects; (c) To exercise the other powers provided for in this Federal Act. 4. The Government of the Russian Federation sets out the standards for assessing the financial sustainability of the developer. 5. Supervisory authority has the right: 1) to control the target use of money paid by the developers on the contract, for the construction (s) of apartment buildings and other (or) other of immovable property under this Federal Law; 2) obtain from the federal executive authority authorized to carry out official statistical information functions, documents and Information needed to monitor the activities of the Developers involved in the construction of multi-family housing units and (or) other real estate objects; 3) receive quarterly reports from the developer Implementation of activities related to the use of funds of the parties to the construction (establishment) of multi-apartment buildings and (or) other real estate objects, including the performance of their obligations under the treaties OF THE PRESIDENT OF THE RUSSIAN FEDERATION 4) to control the activities of developers involved in attracting funds of the parties to the construction (creation) of apartment buildings and (or) other objects of real estate; 5) To monitor compliance with the provisions of this Federal Act, to consider complaints from citizens and legal entities related to violations of this Federal Law; 6. of violations of this Federal Law, OF THE PRESIDENT OF THE RUSSIAN FEDERATION to bring the developers (their officials) to the liability established by this Federal Law and the legislation of the Russian Federation on administrative offences; 8) to apply to the courts for the protection of rights; legitimate interests of equity participants; 9) to exercise other powers under this Federal Act. 6. The developer, who is directed by the controlling authority in accordance with paragraph 6 of Part 5 of this Article, shall have the right to apply to the arbitral tribunal for recognition within three months from the date of the said order. this requirement is illegal. An appeal to an arbitral tribunal with a declaration of acceptance of the said order unlawfully does not suspend its application. The procedure for dealing with such a declaration, the procedure for its consideration and the procedure for deciding on the application for recognition of the order is determined by the law on the proceedings before the arbitral tribunals. 7. The Supervisory Authority has the right to apply to the arbitral tribunal to suspend for a certain period the activity of the developer involved in attracting the funds of the parties involved in the construction (creation) of multi-apartment buildings and (or) other real estate objects, in the case of: 1) more than 30 days in the reporting period provided for by this Federal Law; 2) the developer fails to comply with the regulations financial sustainability of its activities The Government of the Russian Federation; 3) the developer does not meet the requirements of the participants in the construction of the money obligations under Part 2 of Article 12-1 of this Federal Law, and (or) does not comply The obligation to transfer the co-construction site within three months from the date of satisfaction of such claims and (or) performance of such obligation. In addition, the specified requirements in aggregate must be at least 100,000 roubles; 4) the developer was not in compliance with the provisions of this Federal Law, as well as the other normative legal acts adopted under it. Conditions that during the year the developer employed two or more times the measures provided for in this Federal Law. 8. The Supervisory Authority has the right to apply to the arbitral tribunal for the liquidation of the developer in the event of a repeated or gross violation by the developer of the provisions of this Federal Act or other regulatory legal instruments adopted by it. acts, as well as in other federal cases. ". Article 2 Article 25-1 of the Federal Law of 21 on State registration of rights in the Real estate and transactions with it " (Legislative Assembly of the Russian Federation, 1997, N 30, sect. 3594; 2005, N 1, est. (40) The following changes: 1), paragraph 2 should be added to subparagraph 4, reading: "(4) a sponsorship contract if a developer has been designated as a developer as a means of enforcing its obligations."; 2) add the following: " 2-1. State registration of the participation agreement in equity construction, concluded by the developer with the first participant of the equity construction of the apartment house and (or) other real estate, shall be carried out not later than one month from the day The submission of the application and the documents required for the State registration of the participation agreement in the equity construction. After the state registration of the first contract of participation in the construction of the state registration of subsequent contracts of participation in the equity construction of the same apartment house and (or) other real estate object shall be carried out within a period of not more than 10 working days from the day of submission of the application and the documents required for the State registration of the participation agreement in the equity construction. "; 3) to supplement paragraph 3-1 as follows: " 3-1. In addition to the cases specified in article 20, paragraph 1, of this Federal Act, the State registration of the participation agreement may be refused in the following cases: 1) State registration of the other A contract of participation in the equity construction with respect to the same co-construction site; 2) failure to submit a sponsorship contract if, with the State registration of the contract of participation in the equity construction, a developer with the first contributor to the equity construction, the quality of the way to ensure the performance of their obligations under the contract was chosen by sponsorship. "; 4), paragraph 4 should read: " 4. Application to the Single State Register of the avoidance of the participation in the construction of the contract may be submitted by one of the parties to the contract of participation in the equity construction with the application of the documents confirming the termination of the treaty. In the event that a party to the participation agreement unilaterally withdrew from the performance of the contract, a copy of the notice of the other party to the contract for the unilateral refusal of execution of the contract in the form of a contract of execution shall be attached to the application. A letter of departure and, upon the termination of the contract, a copy of the court's decision on the termination of the contract, duly authenticated by the court which handed down the decision. The State Registration Authority, when submitting a declaration by one of the parties to such a treaty, is obliged to notify the other party to the treaty in writing within a working day. ". Article 3 Paragraph 2 of article 26-3 Federal Act No. 184-FZ of 6 October 1999 on the general principles of the organization of legislative (representative) and executive bodies THE RUSSIAN FEDERATION OF THE PRESIDENT OF THE RUSSIAN FEDERATION 5005; 2003, N 27, sect. 2709; 2005, N 1, st. 17, 25; 2006, N 1, sect. 10; N 23, Art. To supplement subparagraph 42-1 as follows: "42-1) State control and supervision of the construction of multifamily buildings and (or) other real estate objects in accordance with the law" Russian Federation on the share building of apartment buildings and other real estate objects; ". Article 4 Article 23.64, Part 2, article 23.64 Russian Federation Code OF THE PRESIDENT OF THE RUSSIAN FEDERATION 1; 2005, N 1, est. (40) Amend the text as follows: " 2. In the case of administrative offences, on behalf of the bodies referred to in Part 1 of this article, the heads of the executive authorities of the constituent entities of the Russian Federation are entitled to exercise control and supervision in the field. Construction of multi-family buildings and (or) other real estate objects, deputy executives. ". Article 5 1. This Federal Act shall enter into force on the date of its official publication, with the exception of article 1, paragraph 17, of this Federal Act. 2. Article 1, paragraph 17, of this Federal Act shall enter into force on 1 January 2007. 3. To the legal relations involving the attraction of funds of citizens and legal entities to share the construction of apartment buildings and (or) other objects of real estate on the basis of the agreement of participation in the construction and arising prior to the entry into force of Federal Act of 30 December 2004 on participation in the construction of multifamily homes and other real estate objects and changes in some The legislative acts of the Russian Federation " (as drafted in this Federal Act) shall apply to the rights and duties that will arise upon the entry into force of this Federal Act. President of the Russian Federation Vladimir Putin Moscow, Kremlin 18 July 2006 N 111FZ