With Radiation Safety Structures In …

Original Language Title: Ar radiācijas drošību saistīto būvju būvnoteikumi

Subscribe to a Global-Regulation Premium Membership Today!

Key Benefits:

Subscribe Now

Read the untranslated law here: https://www.vestnesis.lv/op/2015/238.6


Cabinet of Ministers Regulations No. 661 in Riga on 24 November 2015 (pr. No 62 3) with the radiation safety related structures are Issued in accordance with the provisions of the construction Act, article 5, paragraph 2, first subparagraph and the second subparagraph of paragraph 8 1 General questions 1. determines: 1.1. radiation safety related structures or parts thereof (national ionizing radiation object) (construction) construction process procedures involved in building institutions and responsible būvspeciālist; 1.2. the construction process the necessary documents and their contents; 1.3. the conditions to be included in the building permit; 1.4. where the need to inform the public about the construction plan, and such information; 1.5. derogations harmonisation; 1.6. construction expertise; 1.7. the control of the construction process and the rule of law, accountable institutions; 1.8. building preservation order; 1.9. building location uzmērījum procedure and a procedure acceptable to the building into operation; 1.10. the works guarantee terms after the adoption of the construction operation. 2. Subject to the provisions of the shipbuilding construction which apply environmental impact assessment procedure according to the law "on environmental impact assessment" in article 4, paragraph 1, first subparagraph. 3. On these premises referred to in the provisions of the construction process (except for the works and structures making into) control and the rule of law, the performance of the construction law article 12 of part 1., 3., 4., 5., 5.2, 6, 9 and 10 set out in paragraph būvvald, is responsible for the functions of the national environmental service (hereinafter service), but about control of the works and the acceptance into service of the structure is responsible for the construction of national control Office (hereinafter the Office). 4. Housing construction intentions in drafting the dossier būvkomersant, registered in the register of būvkomersant and who has the right to offer the appropriate service in the field of design. 5. Execution of the būvkomersant according to the laws of radiation safety and nuclear safety requires a license for transactions with ionizing radiation sources. 2. documentation of the construction plans and its development 6. prosecutors agreed with the construction projects of developers of the relevant building plans requires the development and conclusion of the documentation of the relevant contract. 7. before the construction of the conception of the development of the documentation carried out civil design of the preparatory work. The contract for the construction of the conception of the design documentation shall indicate which of the parties undertakes to perform. 8. Contract for construction of the conception development of documentation accompanied the design task, which is an integral part of the contract. The design task to prepare and sign a construction agent and a construction developer. 9. Design task indicates the projected building or change its characteristics, including use, as well as the planning and design of inženiertīkl. If necessary, indicate the specific conditions (for example, the desired constructions or materials, technology, detail a). If the building collapses, the design task specifies requirements for demolition. 10. If the plan provides for the construction of object commissioning through the construction, the design exercise in each round of the fall. 11. The construction conception for the development of appropriate documentation of the construction of laws and regulations governing the municipal development planning of the territory, in accordance with the construction of statutory construction principles of radiation safety and nuclear safety regulatory laws and requirements. 12. If the construction plans in the development documentation in paper form, making it four originals and service, Office, construction projects and proposing developer keep one copy. If the construction plans for the development of the electronic documentation in the form of a document, it shall be submitted in a single copy. 13. When proposing any kind of construction, construction intentions submission (annex 1) add: 13.1. terms of Office of the construction agent, if the construction plans, the application submitted to the authorized person; 13.2. the appropriate way to develop projects of construction minimum; 13.3. technical or specific provisions if they are received before the construction conception for the submission of documentation; 8.3. other documents, permission or consent, if it is determined by law. 14. the reconciliation presented to furnish a general plan of the territory with the structures, facilities and inženiertīkl elements of the attraction of land (hereinafter referred to as the master plan projects) or as a separate agreement to its grounds unambiguous consent to the construction plans. 15. construction of new housing construction for minimal composition includes: 15.1 the explanatory description of planned construction plans; 15.2. a construction master plan clearly visible (M 1:250; M 1:500 or 1:1000 M) on a topographic plan valid; 15.3. floor and roof plans with space or group of spaces and space group explication uses according to the classification of structures; 15.4. the building facade drawings with height marks; 15.5. the intrinsic height of the drawings with cut marks; 15.6. drawings indicating the construction sequence and sequence, if the construction or commissioning is designed by building lots; 15.7. home improvement plan if solution is designed for facilities; 15.8. other documents according to the local authorities planning or lokālplānojum; 15.9. information about a particular Member State of the European Union regulatory framework for the application of a construction development, the application of the Member States of the European Union, the national standards and technical requirements of et seq. 16. Construction projects for placing minimal composition includes: 16.1. an explanatory description of planned construction plans; 16.2. a construction master plan clearly visible (M 1:250; M 1:500 or 1:1000 M) on a topographic plan valid; 16.3. the manufacturer of the finished construction products technical documentation and graphical documents with facades and floor plans with room or group of rooms and premises explication of the group according to the classification of structures; 16.4. drawings indicating the construction sequence and sequence if the construction or commissioning is designed by building lots; 16.5. the home improvement plan if solution is designed for facilities; 10.3. other documents according to the local authorities planning or lokālplānojum; 10.4. information about a particular Member State of the European Union regulatory framework for the application of a construction development, the application of the Member States of the European Union, the national standards and technical requirements of et seq. 17. Construction projects for the restoration of minimal composition include: 17.1. an explanatory description of planned changes, including a description of the radiation safety and nuclear safety and radioactive waste management; 17.2. graphic documents that appear in the planned changes and/or improvements to the building, as well as the facade of the building, or part of the building floors and rooms, if the renewal is for the building. 18. the conversion of the building project for the minimum composition includes: 18.1. interpretative description of planned changes, including a description of the radiation safety and nuclear safety and radioactive waste management; 18.2. construction master plan clearly visible (M 1:250; M 1:500 or 1:1000 M) to a valid plan, changing the topography structures; 18.3. graphic documents that show planned changes of the building; 18.4. the intrinsic height of the drawings with cut marks. 19. Construction projects for the preservation of a minimal composition includes: 19.1. an explanatory description of conservation; 19.2. the necessary conservation work list; 19.3. solutions to the structural loss of stability and construction elements further deterioration; 19.4. solutions to prevent hazards to human life and health or the environment; 19.5. other documents which characterise the building. 20. Construction demolition construction for minimal composition includes: 20.1. explanatory description of planned construction plan, including a description of the radiation safety and nuclear safety and radioactive waste management; 20.2. construction master plan in accordance with clearly visible (M 1:250; M 1:500 or 1:1000 M) to a valid plan, indicating the topography at the nojaucam of the building and the demontējamo inženiertīkl. 21. Construction of minimal composition accompanied by an explanatory description, specifying the following information: 21.1. building plans and planned construction; 21.2. the planned amount and the carrying out of the works; 21.3. the construction sequence and sequence when commissioning is designed by building lots; 21.4. the inženiertīkl dismantled, if such works are intended; 21.5. the planned construction of a waste (radioactive waste) volume and type; 21.6. the planned environmental availability solution if you need to ensure accessibility; 21.7. the planned protected cultural monuments and heritage environmental modifications, if the construction plan intended to realize the cultural the monument protection zone. 3. The construction plans and building permit issue 22. Service building law article 12 paragraph 1 of the fourth part of the time-limit set in the evaluated construction plans specified in these provisions the application and documents and take a decision on the issue of building permits (annex 2) or refusal to issue a construction permit. 23. A permit shall include the following: 23.1. Design conditions, including: 23.1.1. to be part of a construction and other construction-related requirements in detail according to the local government building regulations; 23.1.2. a claim for a construction of solutions with the building owner or legal possessor, if such right tacitly; 23.1.3. provision of technical or special needs from receiving State and municipal institutions; 23.1.4. receipt of technical regulations need inženiertīkl connections (atslēgum) and the crossings; 23.1.5. environmental accessibility requirements, if it is necessary to ensure accessibility; 23.1.6. other legislation in the cases specified in the documents requested, the license, permission or consent; 23.1.7. other claims, including claims to be a façade decoration construction products or their equivalent for the territory planning, detailed or lokālplānojum (if one has been developed); 23.2. the conditions for the commencement of the construction works, including requirements relating to: 23.2.1. documents to be submitted to the responsible būvspeciālist (related articles, autoruzraudzīb); 23.2.2. for registration to submit documents required for fixing process works (public works magazine, autoruzraudzīb magazine, building plan); 23.2.3. documents for works for civil liability compulsory insurance and the responsible būvspeciālist of professional liability insurance (insurance copies); 23.2.4. other documents if required by laws and regulations; 23.3. the deadlines the construction permit conditions. 24. Construction permit conditions include relevant construction plans. If the intended housing preservation, the service can not raise the design conditions. Building permit conditions included in the initiation of construction works enforceable within four years from the making of town planning grades for design conditions. 4. Public Information On the construction of 25 new or conversion of the received planning permission for the construction of the principal law article 14 within the time limits laid down in the seventh part, inform the public, placing būvtāfel (format, not the least of (A) 1, of a material that is resistant to environmental exposure) piece of land, which allowed the construction of the building. 26. Būvtāfel to deploy for a period of not less than building challenge. 27. Būvtāfel in the cities and villages of money against a public place, but outside the cities and villages – against the road. Būvtāfel indicates the following: 27.1. the concept of construction (construction type and address); 27.2. the client (natural person or legal person's name, address, registration number); 16.3. a construction Developer (legal person of the name, address, registration number); 27.4. the intention of the plan with the construction of the building placement; 27.5. information on building permits entry into force, the date of adoption of the decision and the number.
5. Designing of Development Projects 5.1 and it consists of 28 receive a building permit, the Subscriber shall arrange for the building design conditions. The necessary technical or specific provisions require the respective institutions, if they are not received, the drafting of minimum building project. 29. the development of Projects to the extent laid down in these regulations and the necessary construction plans as well as specified in the building permit. 30. the Construction can develop, the application of the other Member States of the European Union of the national standards and technical requirements, et seq if it agreed with the service. Not allowed while several Member States of the European Union or national standards, the application of a single constructive et seq element or one of the engineering system design in the construction of a single object. 31. A construction manager on a construction project and the construction of the cover page of the master plan, which is also the main indicator describes the object, the signature certificate that is included in the construction plan and develop all the necessary parts according to the conditions laid down in the building (annex 3). 32. A construction manager on a construction plan concerned portions of the main drawing page (the General index page) sign a Declaration on the construction of part of the solution to the compliance with the Latvian et seq, and other laws, as well as technical or special regulations (annex 3). 33. If a construction for the development in the application of the other Member States of the European Union of the national standards and technical requirements, et seq construction manager on a construction plan concerned portions of the main drawing page (the General index page) sign a Declaration on the construction of part of the solution to the compliance with the Latvian et seq, and the other, the laws of the Member States of the European Union and national standards et seq of the technical requirements as well as technical or special regulations (annex 3). 34. all parts of the General construction plan for the construction of the signature of the head of the page. 35. some of the parts of the construction drawings or text technical developer sign each page of the drawing or text section. If the developer does not have relevant certificate, signature page, drawing individual parts or a construction manager, which they tested. 36. Building construction (except construction demolition construction) is the following: 36.1. General: 36.1.1. setting up civil design necessary documents; 36.1.2. plot engineering studies; 36.1.3. interpretative description, which contains general information about the shipbuilding technical indicators and key use according to the classification of the structure (including the four-digit classification code), as well as for general information about accessibility solutions; 36.1.4. technical or special provisions; 36.1.5. licences, authorisations and consent; 36.1.6. General index page; 36.1.7. Drawing of the master plan of the construction site in accordance with clearly visible (M 1:250; M 1:500 or 1:1000 M) to the topographic plan if the planned new construction, placement, or work to change the volume of the construction; 36.1.8. the inženiertīkl of the projected plan incorporated in the appropriate scale clearly visible (M 1:250; M 1:500 or 1:1000 M) to the topographic plan if inženiertīkl construction or planned changes in it; 36.2. architecture: site title: 36.2.1 36.2.1.1. territory of the vertical design, where changes in the vertical design of the territory; 36.2.1.2. facilities and greenery plan, where facilities or greenery; 36.2.2. architecture: section 36.2.2.1. graphic documents with Visual solutions and building height marks, if the construction is designed for surface; 36.2.2.2. building floor and roof plans with the building and the room size and room for group use of explication that adds a specific floor plan; 36.2.2.3. building facades with height marks; 36.2.2.4. specific sections with height marks; 36.2.2.5. building materials of construction and specifications; 36.3. inženierrisinājum: 36.3.1. constructions; 36.3.2. the required inženiertīkl (water supply and sewerage; heating, ventilation and air conditioning; power supply; heating supply; the gas; electronic communications networks) and their solutions (connection diagrams, specifications, cuts); 36.3.3. the technical diagrams and calculations. Making the conversion, if you removed the object of ionising radiation, accompanied by detailed object elimination plan; 36.3.4. the construction and building materials specifications; 36.3.5. the installation and fixing of construction drawings and descriptions; 36.3.6. environmental protection and radiation safety and nuclear safety (including environmental radiation monitoring measures); 36.3.7. other inženierrisinājum; 36.4. the work of the organisation of the project; 22.7. fire report: 36.5.1. Description, which includes construction fire safety characteristics; 36.5.2. the master plan of fire protection solutions (structures, construction, external inženiertīkl fire and rescue job security); 36.5.3. fire protection requirements for structures and solutions (for example, forest fire risk assessment and fire zones, structures ugunsnoturīb description, requirements and defining of load-bearing structures, the fire resistance limits and ugunsreakcij classes, building decoration, ugunsslodz, smoke protection solution, claims against the spread of fire and smoke in the event of fire, special fire protection measures, taking into account the particularities of the structure); 36.5.4. emergency evacuation; 36.5.5. protection against explosions if the building intended for the transport of explosive substances, the production, processing or production; 36.5.6. fire protection system (fire detection and alarm systems, fixed fire-extinguishing system, fire notification System smoke and heat control systems); 36.5.7. engineering system of fire protection solutions; 36.5.8. continuous supply providing fire protection systems; 36.5.9. specific fire during operation; 22.7. the technological part: 36.6.1. technological scheme of production processes; 36.6.2. machine layout, diagrams and descriptions; 36.6.3. the production process of technical provisions or descriptions; 22.8. the economic part: 36.7.1. equipment, design and material description summary; 36.7.2. amount of the work; 36.7.3. cost calculation (estimate). 37. the construction of structures demolition has the following components: 37.1. General: 37.1.1. requires the initiation of civil design documents; 37.1.2. plot engineering studies documents the General būvnoteikumo of the cases; 37.1.3. interpretative description that contains information about the buildings demolition method of inženiertīkl construction of dismantled waste management, and recycling or disposal site; 37.1.4. technical or special provisions; 37.1.5. permission and consent; 37.1.6. General index page; 37.1.7. part of the territory: 37.1.7.1. the corresponding construction master plan clearly visible (M 1:250; M 1:500 or 1:1000 M) to the topographical plan. 37.1.7.2. joined the dismantled inženiertīkl plan in accordance with clearly visible (M 1:250; M 1:500 or 1:1000 M) to the topographical plan. 37.1.7.3. the vertical design of the territory; 37.1.7.4. facilities and greenery plan for the territory, if taking; 37.2. the work of organizing the project. 5.2. the work of organizing the content of the project 38. organisation of Work in drafting the entire amount of the works (construction). The organisation of work, the project has the following components: 38.1. interpretative description; 38.2. the master plan of the works; 38.3. the protection plan, which also includes radiation safety and nuclear safety requirements; 23.9. the Works Calendar plan at the request of the Subscriber. 39. the interpretative description describes the General and special conditions of construction, possible difficulties and peculiarities, as well as the total duration of the works and most important environmental measures and recommendations to ensure quality control and the Organization of the construction site. 40. the master plan of the works developed in the individual stages of construction. It noted that existing and newly built in nojaucam construction, temporary structures, permanent and temporary roads, būvmašīn (also Assembly cranes) placement and movement paths, rapper and attract sharp fixing point, inženiertīkl (electricity, water, heat and other resource inženiertīkl), indicating the standing and temporary connection to the site, as well as the material and design of the stowage area. 41. the drafting of the Organization's work in service of the project construction or restoration, conversion to be carried out without interrupting the execution of basic construction work in addition to the organisation of the project specify: 25.5. what works and in what order, to be carried out without interrupting the execution of basic structures, and what works, in what order and within the time limits to be laid down under which the basic execution breaks; 41.2. identified – the works premises functioning is interrupted temporarily or completely; 41.3. interpretative description – measures that have the potential to ensure smooth implementation of the basic construction and carrying out the works; 25.7. the admissibility of the use of the construction works, conditions of use and estimates of the permissible weight of building materials and assembly load on the load-bearing structures. 5.3. Construction of deviations from the technical requirements and coordination 42. If a technical or specific rule requirements cannot be met, a construction of technical solutions consistent with the institutions established by the corresponding requirements. Departures from the technical provisions or the specific time harmonized design. The mark made on the construction plan for the reconciliation of the master plan or technical changes or specific provisions. 43. If the law governing the construction of technical requirements cannot be met, article 9 of the law on construction of the third part of the cases allowed them to coordinate with the relevant national and local authorities. Harmonisation carried out building design conditions during the period. A check mark in the reconciliation is made to construction master plan. 5.4. A construction expertise 44. Construction (except for the demolition of a construction) expertise: 44.1. inženierrisinājum part; 44.2. the organisation of project work; 44.3. the economic part, assessing the economic justification of the choice of materials in accordance with the design of the task, as well as the cost of adequacy of workstations; 27.6. fire safety measures report, as well as the other projects section on fire protection solutions. 45. If facing disputes between participants on the construction plan of the construction of the compliance with the laws and regulations on technical or special requirements, the inspection carried out construction projects or those parts of the sections for which members of the construction is in dispute. 46. the expert opinion of a construction contractor adds a construction documentation. 5.5. coordination and review a construction plan 47. projects developed under the Subscriber and other persons according to the design conditions. 48. in projects Developed four copies of the original and, if necessary, also a construction expertise opinion submitted to the Town Planning Department of the design conditions are due. Service Bureau, proposing projects of construction and developer stores one by one copy of the construction plan. If a construction project in the development of an electronic document, it shall be submitted in a single copy. 49. the Department assessed the adequacy of the construction building design contained in the conditions and regulations. 50. If all the conditions of service of the design construction of article 12 of the law in the fifth subparagraph shall be made within the time limit set in the building of the design mark of the conditions. 51. If the Department finds that not all design conditions or have received all necessary consent or permission, it instructs the customer to recycle construction plan or get the missing consent or permission. 52. the deficiencies found By the client of the evaluation of projects submitted again in building design service conditions within the time limit under this provision, paragraph 48. 53. After the building permit design contained in the conditions of the works submitted to the customer service to initiate the necessary documents. 6. Work 6.1. commencement of the construction works of the Building conditions and the construction time 54. If the building works started in conditions are fulfilled and the customer has provided all the documents specified in the building permit, the Department of law Construction of article 12, fifth paragraph, the deadline: 54.1. construction permit shall specify the works requested by the client, up to the works for civil liability compulsory insurance period, except where the operator works in the insurance contract for all of its objects is to be concluded for the year; 54.2. construction permit shall specify the maximum length of the works under General būvnoteikumo in the stipulated time limit, to which a permit may be extended (the works) and to which building transferable into operation; 54.3. building permits added to building annex (annex 4) which indicates the operator and works of būvspeciālist are invited. 55. during the work of construction workers can change or external būvspeciālist, if you inform the staff and submit new works for compulsory insurance against civil liability in respect of a copy of the insurance policy or the new būvspeciālist article and the context of the professional liability insurance policy copy. The new operator of the construction works or the new būvspeciālist the guest is entitled to initiate the duties on the construction site of the new building of the annex (annex 4), the date of issue. 56. the service can extend the maximum duration of the works by this provision in paragraph 57 of the conditions. 57. If the structure is not put into operation a set deadline and have changed the factual and legal circumstances on the basis of which began construction, the principal law "on environmental impact assessment" in order to carry out initial environmental impact assessment. If you have changed the factual or legal circumstances, the service may decide on municipal territory planning inadequate housing demolition. 58. If, in accordance with paragraph 57 of these provisions is re-evaluating the construction plan, planning permission (the works duration) extended service time, but not more than three years, if the service is shown in the current building cadastral trying thing (the construction to which the legislation is intended to determine the cadastre) and submitted to izpildmērījum plan for shipbuilding, as well as the location of the relevant works for compulsory insurance against civil liability in respect of a copy of the insurance policy. If building within that time-limit is not put into operation and have changed the factual or legal circumstances on the basis of which was launched in the construction, service may decide on municipal territory planning inadequate housing demolition. 6.2. preparation of the Construction works shall be prepared and 59. implementation works. 60. The customer and works for mutual commitments determined in accordance with these rules, the Latvian et seq, and other laws and regulations of the public works contract, which also covers the preparation of the construction works. 61. The Subscriber receives with the execution of the associated permissions and before the commencement of the construction works: 61.1. works issued building permits for a copy of the reviewer marked the start of construction work on the objective conditions and construction; 61.2. in accordance with the laws and regulations in the field of labour protection shall designate one or more of the labour protection coordinators, where the works are performed in more than one works. 62. The construction contractor employing one or more health professionals or to attract competent professionals or institutions according to the laws and regulations in the field of labour protection. 63. If the contractor entered into construction works contracts with individual participants in the works, he works for each individual reviewer shall issue a copy of the building permit. 64. the process of preparation of the works take the necessary organisational measures, as well as work on the construction site and outside it, to ensure the smooth operation of the works and all works membership in coordinated action. 65. The works receive a construction contractor, make sure that a more advanced drawing. If the reviewer has requested the works detailed drawings or even is not developed by them, the works contractor is responsible for the possible consequences. Detailed drawings may develop in the course of the works, and also coordinate with the developer and construction contractor. 66. the main instrument of būvas thus the Subscriber shall be submitted to the Office within seven days from the date of signing of the Act. When the main objective of būvas, but have not yet begun construction work, the main construction contractor shall take the necessary measures to the construction plans of the territory protected against adverse natural and geological phenomena (such as flooding, noslīdeņ), specified in this rule referred to in paragraph 70 works project. 67. before the commencement of the construction works, the existing building conditions, the main operator of the construction marks and delimit danger zones, set the existing underground structures of inženiertīkl and other axes or marks it borders, as well as provide traffic and pedestrian movement and safe access to the existing buildings and infrastructure. These measures work carried out in line with the draft inženiertīkl and affected building owners. 6.3. the documentation of the 68 works. If during the works it is necessary to provide for solutions that are different from those provided for in a construction solutions, their implementation is permitted after the construction of the changes in the law, and the construction of the General būvnoteikumo of the cases and order. 69. The works are organized and carried out in accordance with the construction plan, and its work in organizing the project, as well as the work of the project. 70. the work of the project, based on the developed projects, develop public works contractor (principal investigator of the works), but a separate and dedicated work, the operator of certain works. Work out the components of the project determined in accordance with the laws and regulations on the work of the project, but the project's level of detail is determined by its developer, depending on the nature and extent of the work. 71. Depending on the volume of work and the duration of the proposed construction work out of project development for the building or works in the whole cycle (for example, the underground, the surface for the cycle cycle cycle of preparation of construction, section, span structures, standing). 72. the drafting work of the project to an existing building shall comply with its owner, or, if not, the legal possessor and the situation. 73. If the works projects of the works of the individual investigator, this project shall be coordinated with the main purchasers of the works. On the basis of a mandate issued by the heads of būvkomersant, works in the project approved by the individual performing the works of būvspeciālist. Housing preservation, restoration or conversion work carried out in accordance with the construction plan also projects a developer and contractor. 74. Work out the project shall be referred to the responsible manager before the construction of the works provided for in the commencement of the construction works. 75. the work of the project is available at the construction site workers būvspeciālist and controlling bodies. 76. Public Works Director every working day shall make entries in the journal works to describe the actual situation on the construction site. The works proposed in the journal būvuzraug and autoruzraug the opposition or guidance is considered fulfilled if the būvuzraug or autoruzraug had done the tag works in the journal. Entries in the log for their works to the works carried out and certain works of construction managers whom. 6.4. The works and quality control of 77. labour protection On construction sites, according to competence is responsible for construction work (the main operator of the works), the public works Director in charge, but on individual job types – individual person works construction managers. Construction managers followed the defensive coordinator job. 78. Road transport and self-propelled mechanism motion construction site organized in accordance with the work project, et seq, and the rules of the road. 79. On the quality of the works is responsible for the works. 80. The construction of quality control system for each investigator works develop according to your profile, the type of work performed and amount. Quality control of the works include: 80.1. the documentation of the works, materials, materials supply and construction equipment, machinery and equipment similar to the original; 80.2. individual operations or technological processes control; 49.9. completed (candidate) the type of work or construction cycle (design element) closing control. 81. the inspection Work after full completion of construction is not possible, adopted immediately after the execution, creating cover work receipts. 82. The completed major construction and jobs, as well as segto built in fire protection for important engineering systems (external and internal fire-fighting water supply system, automatic and non-automatic fire protection system) adopted into service with the adoption Act (5, 6 and 7). 83. the continuation of the works is not allowed if the customer or būvuzraug (if the building is being performed) and representatives of the performers of the works is not compiled, and work site signed by previous cover work receipts. If būvuzraug or autoruzraug finds the work carried out by the non-compliance with construction or construction technology requirements, further work should be stopped, a record of the work or the autoruzraudzīb journal and specifying a due date. Work continues only after all signed the cover work of the adoption Act. 84. If the works you create over the break, during which the Act adopted may cover work injuries before the resumption of construction work carried out repeated previous cover verification of the quality of the work and shall draw up a report. 85. the construction contractor quality control general būvnoteikumo of the būvuzraug in the cases specified in the call. 86. The Subscriber autoruzraudzīb General būvnoteikumo for the cases brought by the construction of developers. 87. The Office may require the following basic construction to present the basis for the plan of izpildmērījum if there is a reasonable doubt that the planned object is built, exceeding the construction intentions in the documentation, as well as harmonized distance in the event of a dispute. 6.5. Environmental conditions 88. organizes and carries out the works so that environmental damage would be minimal. Environment and natural resources protection, sanitary and security established in the works are organized and conducted in compliance with the law, within the limits and requirements. The consumption of natural resources must be economically and socially sound. 89. Preserve the restoring, remodeling or demolition of a structure, if possible, take the construction waste recycling and recovery. All construction waste materials, which are to be classified as hazardous waste, managed according to the regulations on the management of hazardous waste and radioactive waste is managed according to the regulations on radioactive waste and related material. 90. before the ground work, as well as through gliding jobs construction site, soil is removed and stored for future use. 91. If in the construction site of industrial and domestic sewage pollution degree is greater than the specified regulatory signs before entering the sewer network, it cleans up according to laws and regulations in the field of prevention of pollution. 92. It is not permissible for water (also stripped) discharge from the site itself and not the path of the channels. Water discharge and the open nature of the system of novadgrāvj provides for works projects. 93. the process of drilling work, reaching the water sējhorizont, not make arrangements to prevent overuse of ground water discharge and water sējhorizont pollution. 94. Reinforcing the soil, prevents ground water and open water pollution. The necessary measures shall carry out the work project. 95. The construction process can change the natural terrain and hidroģeoloģisko conditions (for example, fill up a career, dig ponds, installing a drain), if those measures are intended for construction or as determined by the Geotechnical Control Office (Geotechnical work carried out in the course of construction, to establish the conformity of the construction plan of the actual geotechnical data and, if necessary, adjust the construction). 6.6. Housing Preservation works in the event of termination or suspension 96. Building preservation works performed if a termination or suspension may occur because of the danger to the environment or to human life and health or dangerous defects may occur in structures. 97. the decision on the suspension of the works may accept contractor by giving service and Office. 96. These provisions in the case referred to in paragraph 1 before the termination of the works submitted to the coordination services of the principal building conservation works project. 98. the housing preservation activities the project specify: 98.1. any necessary expenditure list; 98.2. solutions building loss of stability and construction elements further deterioration; 98.3. solutions to prevent hazards to human life and health or the environment; 98.4. shipbuilding activities calendar in the preservation plan. 99. If the authority which are not under the competence of the Department stopped the works, the authority shall immediately notify the Department. 100. the Department, in cooperation with the Bureau within 30 days after that rule 97, paragraph 99, and on receiving the surveyed object (except when the works stopped) and adopt a decision on the authorisation to suspend the construction work, conservation works project or, if necessary, shall take a decision on the housing preservation. 101. If, after a survey found the object of constructing conservation need and the client does not submit the service building conservation works project, the Department of housing preservation decisions: 101.1. the reasons for the housing preservation; 101.2. conditions of housing preservation (including the measures to be taken to ensure the safety of construction design, stability and integrity, as well as, where necessary, the construction work of the conservation project); 101.3. building conservation works project submission. 102. the service within 14 days of building conservation works project, the assessment of its conformity with the requirements of the laws under it or adopt a decision specifying the identified deficiencies and their prevention. 103. following these rules in the decision referred to in paragraph 102 of the execution the customer resubmit service building conservation works project. 104. the housing preservation jobs attributable works requirements, including the requirement for public works for civil liability compulsory insurance. Works for civil liability to be insured to the entire work period of preservation. 105. The work shall end with the moment when the service has adopted a decision on the suspension of the work or when the client has finished the construction works under the conservation service agreed the shipbuilding activities in the preservation project. 106. If the client fails to fulfil the requirements of this regulation, the service is entitled, upon notice to the Subscriber, to carry out conservation works of construction. All structures associated with preservation costs shall be borne by the Subscriber. 107. If after the termination of the works later in the period, the Department finds that the construction can cause hazard to the environment or human life and health, or that it is dangerously damaged structures, service shall decide on the housing preservation in this chapter, in that order. 108. If, after suspension of the Works Department or the Office finds that the required housing preservation, service shall decide on the housing preservation in this chapter, in that order. 7. acceptance into operation and demolition work on the construction of 109. adoption into adoption or acceptance of the demolition contractor proposes. Before the adoption of the proposed construction, civil engineering, carried out: 109.1. external inženiertīkl, horizontal and vertical sites izpildmērījum, indicating the amounts according to the civil engineering civil engineering type volume indicators, but in the case of renewal or modification of izpildmērījum shall be carried out if the situation has changed in the area; 109.2. building cadastral trying under the regulations to the Act concerning the cadastral structures determine, except when the building is demolished or made its preservation. 110. at the written request of the principal bodies which are issued by technical rules, checks and 14 days following receipt of the appropriate competence shall deliver an opinion on the shipbuilding operations or readiness, building demolition, its compliance with the technical regulations and the requirements of the law. 111. at the written request of the contractor within 14 days of the receipt of the State fire and rescue service provides an opinion on the compliance of the fire safety construction requirements, but the health inspectorate – compliance with minimum hygiene requirements, if a candidate for the construction are legislation certain minimum hygiene requirements. 112. the adoption of the Proposed construction or demolition work in the operation, the client shall submit the following documents to the Office: 112.1. proof of readiness for operation of the construction or demolition of buildings (8 and 9); construction of 112.2. documentation on the affected parts if the changes at the time of the works be allowed to perform in accordance with General provisions; construction site izpildmērījum 112.3. plan with the terrain and the structure height marks, except where the building torn down or its preservation; 112.4. building cadastral Affairs, determine which prepared under the regulations to the Act concerning the cadastral structures determine, except when the building is demolished or made its preservation; 110. these rules 112.5. and institutions referred to in paragraph 111 of the findings; 112.6. significant design and cover the adoption of legislation work, except where the building torn down; 112.7. works journal; 112.8. technological equipment provided for construction, special systems and equipment inspection records and receipts, as well as compliance with the supporting documentation, except where the building torn down or its preservation; 112.9. built-in compliance of products supporting documentation; 112.10. autoruzraudzīb journal, if the work is carried out in the laws of the autoruzraudzīb in the order; a construction developer 112.11. opinion on the conformity of the construction works, if not autoruzraudzīb; 112.12. būvuzraug report on the implementation of the plan of the building, where the works are carried out on the building regulations in the order; construction technical survey 112.13., if the construction carried out preservation. 113. This rule 112.1.,.,., 112.4 112.2 112.3.,.,., 112.6 112.11 112.12. and 112.13. referred to copies of documents shall be deposited in the Office of the principal. 114. The works takes office. Call the Office to participate in the decision-making officers. 115. The principal investigator of the works by or its authorized representative, presented the Office construction or building site. 116. the Office's task is to assess the operational readiness of the construction or building demolition and marshalling work areas on the basis of these provisions to the Office referred to in paragraph 112 of document, as well as compliance with laws and regulations in the field of construction and construction. 117. The Office shall have the right of adoption or building construction demolition making invite būvuzraug and construction of developers. 118. the Office is not entitled to adopt a construction service or accept the demolition of the building, if any of these rules or 111.110. institutions referred to in points is not given a favourable opinion on the adoption of the operational readiness of the construction or demolition of the building. 119. round structures may be accepted into its works are completely finished, and all the relevant structures for fire safety, turn work and environmental protection measures, as well as the entire construction made in order to ensure the availability of the environment. 120. Pārbūvējam or renewable construction inženiertīkl construction which is issued to the construction of a single building permit, allowed to add into the existing inženiertīkl and launch it into operation before the construction Act received acceptance into service (hereinafter referred to as the Act) (annex 10), if on the inženiertīkl the adoption of operational preparedness according to the construction plan, and izpilddokumentācij has signed this provision in paragraph 110 above. 121. the Office within 14 days after receipt of the proofs of the shipbuilding operations or readiness, in conjunction with the demolition of the construction or building site subscriber reporting period, adopt the performance works, drawing up the Act, or, if the building torn down, shall issue a certificate on the premises not being (annex 11), or decide on the known deviations. 122. a number of Acts are as follows: 122.1.14 the first two characters – the year the last two digits; 122.2. next five marks – the registration number of the Act, which is up to five characters with zeros from the left; 122.3. last seven signs-construction of the territorial code under the administrative and territorial units. 123. The Act specifies the Subscriber and the operator of a harmonised construction period, a Subscriber may request that the contractor works on its own means, eliminate the construction defects (gaps), which discovered after acceptance of the works. That period, counting from the date of signing of the Act, must not be less than 10 years. 124. The Act shall be made four copies. Two copies shall be given to the customer, one copy to be kept in service and Office. Act shall be drawn up in a single original, if it is prepared in electronic form of a document. 125. If, based on the construction and building permits, operating more than is assumed in the building in the sixth section of the Act "the shipbuilding technical economic indicators" fills in each building separately. 126. If a construction for landscaping of the territory, but this is not done, the Office may accept the construction of the service or to accept the construction demolition work, providing that the work of the regional planning completion delayed for up to 10 months, but not longer than 1 June of the following year. 127. In accordance with the provisions of paragraph deferred 126 works and their completion record deadlines in the Act or in the absence of the construction certificate. Act or certificate on absence of construction that delayed completion of the works within the control of the Office building. 128. the building is deemed to be accepted into service after it is signed. 129. Building considered to break down after you have signed the statement of absence of construction. 130. If the works carried out do not meet the accepted conception or construction of regulatory laws, the Office identified in the decision on derogations specify indents and established deadlines for the correction of these derogations. 131. by this provision in paragraph 130 that decision contains derogations of the prevention client repeatedly go to the Office, submit the documents specified in the decision. If the customer has prevented a decision contains derogations, the Office shall take place in operation, creating legislation, shall issue a certificate on the premises or not. 132. the owner of the Building or, if not, the legal possessor of the corresponding real estate cadastre of the State law after the adoption of the civil engineering service presented the State land service registration or updating data in the real property cadastre of the State information system on engineering structures and izpildmērījum of the adoption plan. Prime Minister, Minister of the Prime Minister's duties, traffic Executive Richard Kozlovsk by economic Minister Dana Reizniec-annex 1 oak Cabinet 24 November 2015 regulations no 661 national environmental service construction plans for the construction of application agents (natural persons first name, last name or legal name of the person) (natural person or legal person code registration number) (domicile, legal address, phone number) (electronic mail address) please consider submission of construction plans (construction) construction/demolition.
The real property cadastre number 1. Construction type (required mark): new construction;   rebuilding; restore;     demolition;   placement;  preservation.

2. details of the object: the construction group 2.1 (General provisions) 2.2 the main uses of construction (according to the classification of structures) 2.3. construction expected height (in metres) 2.4. construction surface floor building building 2.5 square 2.6. construction of the required inženiertīkl 3. details of the plot: 3.1 land cadastral designation of the unit 3.2. land units address 3.3 land owner, or, if not, the legal possessor and/or user (physical person's name first name, last name, social security number, or the name of the legal person registration No.)
3.4. If a construction for the forest: 3.4.1. number of forest blocks and _____ _____ _____ _____ _____ 3.4.2. nogabal number _____ _____ _____ _____ _____ 3.4.3. atmežojam area by the forest of nogabal _____ _____ _____ _____ _____ 4. details of an existing building or part of it: 4.1 Construction Group (General provisions) 4.2 building cadastral designation 4.3. construction the main use (according to the classification of structures) 4.4 housing 4.5 construction owner address or, if not, the legal possessor and/or user (physical person's name first name, last name, social security number, or the name of the legal person registration No.)
4.6 construction required removal of 4.7 inženiertīkl. intended building demolition method 4.8. waste (including radioactive wastes) demolition and marshalling areas place 4.9 4.10. type of space group designation of the cadastre 4.11 space groups use (according to the classification of structures) 5. Authorised person (an individual's name, surname, personal code, place of residence, telephone number, electronic mail address or legal name, registration No., address, telephone number) of the person specified in (name of contact person first name, last name, ID number, phone number, e-mail address) 6. A construction Developer (legal name, registration No., registration no būvkomersant, registered office, telephone number) 7. Construction Developer's information on the planned construction of the composition, it takes part in the development of section 8. information about a particular Member State of the European Union regulatory framework for the application of a construction development, applying the European Union Member States ' national standards and technical requirements of et seq (Member State of the European Union) 9. Construction developer certificate : Solutions meet the construction laws governing local authorities and binding rules.
A construction Developer (first name, last name, signature of the official veterinarian) (date) 10. Answer to the construction plans and planning permission application, I would like to receive (specify one of the ways): by mail to the address indicated in the application; with electronic mail, using a secure electronic signature _____ _____ _____ personally national environmental service. 11. Request for additional information (documents) and/or a decision on extension to the response to send electronically to the electronic mail address ___ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ 12. proposing the construction of the proof: 12.1. Declare that the property attached supporting documents (copies) are authentic, truly and completely, for the object is not a burden, prohibition or dispute. Undertake to implement all or part of a building new construction, reconstruction, alteration, or demolition of the place (the necessary to underline) according to the plans drawn up documentation.
The construction of the proponent (name, surname, signature of the official veterinarian) (date) 12.2. Certify the existence of an area landmark and their compliance with the land boundary plan (if construction takes place outside of cities and villages).
The construction of the proponent (name, surname, signature of the official veterinarian) (date) 13. – the documents submitted in the annex (according to the situation, the required mark): a construction of minimum composition to ____ ____ ____ ____ pages if the construction for forest-land boundary plan with a marked atmežojam for construction in forest land and forest land atmežojam sketch, prepared according to the laws and regulations on tree felling of the forest in the ____ ____ ____ ____ pages or part of the construction technical survey opinion on ____ ____ ____ ____ pages proposing to mandate the construction of ____ ____ ____ ____ pages reconciliation with third parties on _____ _____ _____ _____ _____ _____ _____ pages with institutions on reconciliation __ _____ _____ _____ _____ _____ _____ _____ _____ pages _____ _____ _____ _____ _____ _____ _____ _____ the technical rules on the _____ _____ pages other documents _____ _____ _____ _____ _____ _____ _____ to _____ and _____ pages fill in the national environmental guard 14. Marks for issuing a building permit building permit number date national environment Officer (job title, first name, last name, signature of the official veterinarian) (date) 15. Decision on the refusal to issue building permit decision number date national environment Officer (job title, first name, last name, signature of the official veterinarian) (date) notes. 1.1 document property "signature" does not fill in, if an electronic document is drawn up According to the law on electronic document design. 2. Construction of the intentions of the relevant application to the aisles extended if necessary to reflect more information. 3. the premises or part of the rebuilding, reconstruction or demolition of construction intentions in the event the application fills in the extent that characterizes the building or part of the changes. Economy Minister Dana Reizniec-annex 2 Oak Cabinet 24 November 2015 regulations no 661 national environmental services _____ _____ _____ _____ _____ _____ _____ _____ _____ _____ (address and contact information) construction permit no. _____ _____ (construction permit issuance) Issued on (date) (building agent-an individual's name, surname, personal code, place of residence or entity name, registration No., address, telephone number) for construction/demolition. (object name)
1. type of Construction (required mark): new construction;   rebuilding; restore;     demolition;   placement;  preservation.

2. details of the object: the construction group 2.1 (General provisions) 2.2 the main uses of construction (according to the classification of structures) 2.3. construction expected height (in metres) 2.4. construction surface floor building building 2.5 square 3. details of the plot: 3.1 land cadastral designation of the unit 3.2. land units address 3.3 land owner, or, if not, the legal possessor and/or user (physical person's name first name, last name, social security number, or the name of the legal person registration No.)
3.4. If a construction for the forest: 3.4.1. number of forest blocks and _____ _____ _____ _____ _____ 3.4.2. nogabal number _____ _____ _____ _____ _____ 3.4.3. atmežojam area by the forest of nogabal ____ ____ ____ ____ ____ ____ 4. details of an existing building or part of it: 4.1 Construction Group (General provisions) 4.2 building cadastral designation 4.3. construction the main use (according to the classification of structures) 4.4 housing 4.5 construction owner address or, if not, the legal possessor and/or user (name of legal person , registration No.)
4.6 construction required removal of 4.7 inženiertīkl. intended method of construction demolition waste volume 4.8 and 4.9. getting the place territory type 4.10 groups cadastral designation 4.11 space groups use (according to the classification of structures) 4.12 4.13 address classroom group. the group owner of the premises or, if not, the legal possessor and/or user (name of legal person registration No.)
5. A construction Developer (legal name, registration No., registration Nr. būvkomersant)
6. Planning (detailed in lokālplānojum,) the primary use (papildizmantošan) construction site 7 (the date of the survey) the design conditions 8. Design conditions (required mark): 8.1.  reconciliation with third parties: with adjacent property owners, co-owners: (property address) (property address) 8.2.  Reconciliation (technical provisions): with public authorities: (name, address, contact info) (name, address, contact information) with municipal institutions: (name, address, contact info) (name, address, contact information) by the holders of the inženiertīkl: (name, address, contact info) (name, address, contact info) (name, address, contact info) (name, address, contact info) 8.3.  other institutions the license, authorization and reconciliation: (name, address, contact info) (name, address, contact information) 5.2.  accessibility requirements: access to the facilities of area roads, streets, pavements, walkways pedestrian crossing for the chance to move from one level to another height, especially for persons with functional disabilities handicapped parking number not less than _____ _____ _____ building entrance, especially regarding the possibility to move from one level to another height, especially for persons with functional disabilities movement between the buildings standing for persons with functional disabilities indoor picture : sanitary technical premises to other premises ___ ____ ____ ____ ____ ____ corridors and escape routes to 8.5.  construction consists of: general architecture: the architectural section of the territory of inženierrisinājum title: construction inženiertīkl: water supply and sewerage heating ventilation and air conditioning electricity heating gas supply electronic communication networks technical diagrams and calculations to environmental protection and radiation safety and nuclear safety (including environmental radiation monitoring measures) of construction and building materials specifications other inženierrisinājum _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ the job of organizing the project overview technological fire of the economic part of the additional requirements for the construction of detalizāc information in accordance with local building rules ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ___ 8.6.  construction development, applying the (European Union) national standards and technical requirements of 5.4 et seq.  construction expertise 8.8.  requirements of the facade decoration materials used 5.5.  other requirements for the planning, lokālplānojum or detailed (if any develop) 9. Design conditions (date) the commencement of the construction works conditions 10. Commencement of the construction works within the national environmental service conditions in the documents to be submitted (the required mark): works for civil liability compulsory insurance certificate and a copy of the responsible būvspeciālist the professional indemnity insurance policy public works Director in charge of the copy of the article būvuzraug of the commitment the responsible commitment of article building plan for public works magazine autoruzraudzīb magazine autoruzraudzīb information on works contract analyst (name of legal person , registration No., registration Nr. būvkomersant)  information about defensive coordinator (first name, last name, ID number, phone number), where the works are performed by more than one reviewer of the works other documents, if provided for by law the national environmental service officer (position, name, surname and signature of the official veterinarian) This town planning (administrative) within a month of its entry into force may be challenged in the administrative process law (name, address) the national environmental service marks and decisions 11. Mark for design conditions (date) the national environmental service officer (job title , name, surname and signature of the official veterinarian) (date) 12. Commencement of the construction works due to conditions at the marks made on the design conditions. Commencement of the construction works, the conditions must be satisfied within a period of four years, until (date) 13. Mark the commencement of the construction works conditions (date) the national environmental service officer (position, name, surname and signature of the official veterinarian) (date) 14. After carrying out of public works mark the launch conditions, the maximum duration of the works _____ _____ _____ _____ _____ years: 14.1. works to be taken up (date) 14.2. performing the works of compulsory civil liability insurance policy the insurance period specified in 14.3. building commissioning carried out until (date) the national environmental service officer (job title , name, surname and signature of the official veterinarian) (date) 15. Permit extended until (date) the national environmental service officer (position, name, surname and signature of the official veterinarian) (date) notes. 1.1 document property "signature" does not fill in, if an electronic document is drawn up according to the law on electronic document design. 2. Building permits in the relative box expandable if necessary to reflect more information. Economy Minister Dana Reizniec-oak annex 3 Cabinet 24 November 2015 the rules no Proof samples 661 Construction Manager certification in the construction plan and includes all the necessary parts developed according to conditions laid down in the building.
A construction supervisor (first name, last name, certificate No.) (date) (signature of the official veterinarian)
A construction manager construction plan of the proof This ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ part solutions meet the Latvian et seq, and other laws, as well as the provision of technical or special requirements.
Part of a construction supervisor (first name, last name, certificate No.)
(date) (signature of the official veterinarian)
A construction manager for This building project of apliecinājums2 _____ _____ _____ _____ _____ _____ _____ _____ _____ part solutions meet the Latvian et seq, and the laws of other Member States of the European Union and national standards et seq of the technical requirements as well as technical or special requirements.
Part of a construction supervisor (first name, last name, certificate No.) (date) (signature of the official veterinarian)
The notes. 1.1 document property "signature" does not fill in, if an electronic document is drawn up according to the law on electronic document design. 2. (2) If a construction designed by applying to the Member States of the European Union, national standards and technical requirements of et seq. Economy Minister Dana Reizniec-oak annex 4 Cabinet 24 November 2015 regulations no 661 national environmental service construction permit No. Annex No. (date)
1. the participants in the works (legal name, registration No., registration No. būvkomersant, licence activities with ionizing radiation sources, legal address, phone number) 2. Guest būvspeciālist: 2.1. responsible public works Director (an individual's first name, last name, certificate No., license activities with ionizing radiation sources no.)
2.2. responsible būvuzraug (legal name, registration No., registration No. būvkomersant, licence activities with ionizing radiation sources no.)
2.3. responsible autoruzraug (legal name, registration No., registration No. būvkomersant, licence activities with ionizing radiation sources no.)
2.4. the defensive coordinator (an individual's first name, last name, ID number, phone number) the national environmental service officer (title) (first name, last name, signature of the official veterinarian) (date) notes. 1.1 document property "signature" does not fill in, if an electronic document is drawn up according to the law on electronic document design. 2. in the annex the relevant building permit column expandable if necessary to reflect more information. Economy Minister Dana Reizniec-oak annex 5 cabinet 24 November 2015 regulations no 661 Significant design acceptance report __ ____ of _____. ____ ____ ____ 1. Facility name and address 2. name 3. Construction of agents (natural persons name, surname, personal code, place of residence or entity name, registration No., address and telephone number) 4. Panelists: 4.1 Construction Contractor's representative (name and title) 4.2 Construction Developer (autoruzraug) (the word first name, last name and title) 4.3 Construction agent representative (būvuzraug) (name and title) 5., the Commission carried out inspections (external test) and the verification of the quality of structure, which set up the Commission found 6:6.1 Acceptance of such structures presented to: (list of design and short description) 6.2 are fulfilled in accordance with the Work (a construction Developer's legal name, the name of a construction and drawing no.) 6.3. Structures uses the following materials and articles: (specify the certificates or other documents proving the quality) 6.4. A work in progress/deviations from the construction plan is not a (not applicable). Deviations agreed with (institution, drawing no and date of harmonisation) 7. Commission decision: the work is undertaken in accordance with the construction plan, et seq, and standards, and they are adopted.
The participants in the work of the representative (name) (signature of the official veterinarian) a construction Developer (autoruzraug) (name) (signature of the official veterinarian) Construction agent representative (būvuzraug) (name) (signature of the official veterinarian) Note. 1 document properties "date" and "signature" does not fill in, if an electronic document is drawn up according to the law on electronic document design. Economy Minister Dana Reizniec-annex 6 an oak Cabinet 24 November 2015 regulations no 661 Cover work acceptance report ______. year _____. ____ ____ ____ 1. Facility name and address 2. name 3. Construction of agents (persons name, surname, personal code, place of residence or entity name, registration No., address and telephone number) 4. Panelists: 4.1 Construction Contractor's representative (name and title) 4.2 Construction Developer (autoruzraug) (name and title) 4.3 Construction agent representative (būvuzraug) (name and title) 5., the Commission carried out inspections (external test) and the verification of the quality cover papers that met the Commission found 6:6.1 acceptance show (a short description of the work) 6.2 works executed under (a construction Developer's legal name, the name of a construction and drawing no.) 6.3. in carrying out the work, used the following materials, design and products: (specify the certificates or other documents proving the quality) 6.4. A work in progress/deviations from the construction plan is not a (not applicable). Deviations agreed with (institution, drawing no and date of harmonisation) 7. Commission decision: the work is undertaken in accordance with the construction plan, et seq, and standards, and they are adopted.
The participants in the work of the representative (name) (signature of the official veterinarian) a construction Developer (autoruzraug) (name) (signature of the official veterinarian) Construction agent representative (būvuzraug) (name) (signature of the official veterinarian) Note. 1 document properties "date" and "signature" does not fill in, if an electronic document is drawn up according to the law on electronic document design. Economy Minister Dana Reizniec-oak annex 7 Cabinet 24 November 2015 regulations no 661 for significant fire protection engineering systems acceptance report ______. year _____. ____ ____ ____ 1. Facility name and address 2. Engineering system name 3. Construction of agents (persons name, surname, personal code, place of residence or entity name, registration No., address and telephone number) 4. Panelists: 4.1 construction contractor's representative (name and title) 4.2 construction Developer (autoruzraug) (name and title) 4.3 construction agent representative (būvuzraug) (name and title) 5. The Commission shall carry out the work quality and uptime verification system that made (the name of the legal person, no registration and registered office) 6., the Commission found: 6.1. making a reported (System or system in General Assembly round) 6.2 system installed in accordance with the relevant sections of the construction (design date name, number, drawing number) and the system of equipment used, the equipment and materials 6.3 technical specifications system assembled the following basic equipment, devices and materials: No. p. k. The name of the type, mark, number notes Unit 6.3.1.           6.3.2.           6.3.3.          
7. The harmonized system technical project is not/is allowed (not applicable) the derogations from this project. Deviations agreed with (institution, drawing no reconciliation date and specify which compensatory measures are taken) 8. Act the following documentation (required mark): a system of technical equipment and devices the passport system plant, equipment and materials, the system of the Declaration of conformity of the operational documentation (instruction) other technical documentation that describe the system and its operational parameters (necessary record) 9. Commission decision: is built according to (System or system in General Assembly) for a construction , et seq, and standards. The system is accepted and ready for operation.
The participants in the work of the representative (name) (signature of the official veterinarian) a construction Developer (autoruzraug) (name) (signature of the official veterinarian) Construction agent representative (būvuzraug) (name) (signature of the official veterinarian) Note. 1 document properties "date" and "signature" does not fill in, if an electronic document is drawn up according to the law on electronic document design. Economy Minister Dana Reizniec-Annex 8 Oak Cabinet 24 November 2015 regulations no 661 proof of construction readiness of all or part of the operation of the Construction agent (an individual's first name, last name or legal name of the person) (natural person or legal person code registration number) (domicile, legal address, phone number) declare that (building or part thereof) that the works carried out on the basis of the planning permission no _____ and _____ which _____ _____ _____ _____ (date) issued by the national environmental service , is completed.
1. News about the built object: 1.1. construction group (General provisions) 1.2. construction the main use (according to the classification of structures) 1.3. shipbuilding (metres) in height 1.4. construction surface floor construction building 1.5 1.6 construction area total area būvtilpum m2 m3 shipbuilding 1.7 1.8. construction structural design, material and finish: 1.8.1 1.8.2. vertical structure basics of 1.8.3. intermediate floors 1.8.4. roof construction of 1.8.5 roofing 1.8.6 facade finish 1.9. building ugunsnoturīb rate 2. details of the plot in which the construction: land units 2.1 cadastral designation 2.2. ground unit address 2.3. owner of the land or, failing that, the legal possessor and/or user (an individual's name, social security number, or the name of the legal person registration No.)
3. details of the building or part thereof in which the construction: the construction group 3.1 (General provisions) 3.2 building cadastral designation 3.3 construction the main use (according to the classification of structures) 3.4. premises address 3.5. construction the owner or, if not, the legal possessor and/or user (name of legal person registration No.) 3.6. the total area of construction (that works/building together) _____ ____/____ ____ m2 3.7 construction būvtilpum (that works/building together) _____ _____/_____ ____ 3.8 m3 groups cadastral designation 3.9. groups use (according to the classification of structures) 3.10. groups total area ____ _____ _____ m2 4. details of construction: 4.1 construction started and completed on (date) to (date) 4.2 building or part thereof complies with the construction plan, developed by (name of legal person , registration No., registration Nr. būvkomersant)
4.3. changes and deviations from the agreed projects/no (delete as appropriate) allowed. Deviations agreed and marked in accordance with the procedure laid down in the technical documentation in the implementation of the construction plan 4.4 participated in the following construction works: 4.4.1. reviewer (legal name, registration No. būvkomersant, licence, registration No., address, telephone number) 4.4.2. responsible public works Director (an individual's first name, last name, certificate No.) 4.4.3. būvuzraug (an individual's first name, last name, certificate No.) 4.4.4. a construction Developer (autoruzraug) (an individual's first name, last name, certificate No.)
5. Declares that: 5.1. construction or a part thereof is ready for adoption into 5.2. all of the debris, which are classified as hazardous waste, is buried under the legislation requirements for hazardous waste disposal projects in 5.3 of technological equipment, specialty systems and equipment is installed, checked and adjusted according to project and comply with the laws and regulations in the field of construction projects in 5.4 fire protection, hygiene, acoustic and environmental accessibility requirements are met and comply with legislative requirements by building 5.5 or its part into the adoption of _____ years atklājušo works of construction defects investigator will remove, at its own expense, 5.6 construction total cost is _____ _____ euro, including public law legal persons, policy instruments of the European Union or other foreign financial help features-_____ _____ Euro 5.7 outstanding works (territory greening, a fragment of the facade decoration) will be completed in the following scope and limits: No. p. k. The name of the unit of work completion date Quantity 5.7.1.         5.7.2.         5.7.3.        
The construction of the initiator (client) (name) (signature of the official veterinarian) (Date1) public works contractor (name) (signature of the official veterinarian) (Date1) public works Director responsible (name) (signature of the official veterinarian) (Date1) Būvuzraug (name) (signature of the official veterinarian) (Date1) a construction Developer (autoruzraug) (name) (signature of the official veterinarian) (Date1) notes. 1.1 document properties in the "signature" and "date" does not fill in, if an electronic document is drawn up according to the law on electronic document design. 2. proof of relevant columns extend if necessary to reflect more information. 3. in the case of the housing preservation certificate shall be completed as far as preservation. Economy Minister Dana Reizniec-oak 9. attachment Cabinet 24 November 2015 regulations no 661 proof construction demolition construction agent (an individual's first name, last name or legal name of the person) (natural person or legal person code registration number) (domicile, legal address, phone number) declare that (construction) demolition work carried out on the basis of the planning permission no _____ and _____ which _____ _____ _____ _____ (date) issued by the State Environmental Department is complete.
1. details of the demolished structure: the construction group 1.1 (General provisions) 1.2. building cadastral designation 1.3. premises the main use (according to the classification of structures) 1.4. building address 1.5. construction the owner or, if not, the legal possessor and/or user (an individual's name, social security number, or the name of the legal person registration No.)
2. details of the plot, which made building demolition works: land units 2.1 cadastral designation 2.2. land units address 2.3. owner of the land or, failing that, the legal possessor and/or user (an individual's first name, last name, social security number, or the name of the legal person registration No.)
3. details of construction: 3.1 construction started and completed on (date) to (date) 3.2 construction demolition carried out in accordance with the construction plan, developed by (name of the legal person, registration No., registration Nr. būvkomersant)
3.3. changes and deviations from the agreed projects/no (delete as appropriate) allowed. Deviations agreed and marked in accordance with the procedure laid down in the technical documentation in the implementation of the construction plan 3.4 participated in the following construction works: 3.4.1. reviewer (legal name, registration No. būvkomersant, licence, registration No., address, telephone number) 3.4.2. responsible public works Director (an individual's first name, last name, certificate No.) 3.4.3. būvuzraug (an individual's first name, last name, certificate No.) 3.4.4. a construction Developer (autoruzraug) (an individual's first name, last name, certificate No.)
4. Certify that: 4.1 building is torn down; 4.2. all waste classified as hazardous waste, is buried under the legislation requirements for disposal of hazardous waste inženiertīkl, 4.3 technological equipment, specialty systems and facilities are dismantled according to the construction plan 4.4 total costs of construction are _____ and _____ euro, including public law legal persons, policy instruments of the European Union or other foreign financial help features-___ ___ ___ ___ Euro 4.5. outstanding works (territory greening, utilities) will be completed in the following scope and limits : No. p. k. The name of the unit of work completion date Quantity 4.5.1.         4.5.2.         4.5.3.        
The construction of the proponent (name) (signature of the official veterinarian) (Date1) public works contractor (name) (signature of the official veterinarian) (Date1) public works Director responsible (name) (signature of the official veterinarian) (Date1) Būvuzraug (name) (signature of the official veterinarian) (Date1) a construction Developer (autoruzraug) (name) (signature of the official veterinarian) (Date1) notes. 1. the document properties in the "signature" and "date" does not fill in, if an electronic document is drawn up according to the law on electronic document design. 2. proof of relevant columns extend if necessary to reflect more information. Economy Minister Dana Reizniec-oak 10. attachment Cabinet 24 November 2015 regulations no 661 Act Code of (building or part of a name, address, if not, location and land cadastral designation of the unit) acceptance into service (the Act of picking location) on (date) 1. Construction type (required mark): new construction;   rebuilding; restore;     placement;    preservation.

2. Construction of agents (natural persons first name, last name or legal name of the person) (natural person or legal person code registration number) (domicile, legal address, phone number) 3. Making work out of State Construction control Office: 3.1.  (position, name, surname) 3.2.  (position, name, surname) 3.3.  (position, name, surname)
4. Hire guest: 4.1 būvuzraug (an individual's first name, last name, certificate No.) 4.2. a construction Developer (autoruzraug) (an individual's first name, last name, certificate No.) 4.3. construction performer (legal name, registration No., registration no būvkomersant, registered office, telephone number) (specialty, position, name, surname) 4.4. National Environment Services 5. Building national control Office met: 5.1 the transfer of construction of ____ ____ ____ volumes 5.2. execution of works execution and documentation: 5.2.1 construction Journal No ____ ____ ____ 5.2.2. autoruzraudzīb Journal No. ____ _____ ____ 5.2.3. significant design and cover the work of the receipts to the _____ and leaves _____ ____ ____ ____ the volume (s) 5.2.4. būvuzraug report on the implementation of the plan of the building to the __ _____ pages 5.2.5. electrical inspection documentation to _____ and _____ pages 6. Construction national control Office evaluated: 6.1. proposing the construction of the evidence or part of a building ready operation 6.2. the following State, municipal and other authorities opinions: 6.2.1.  (body) (date) opinion No. on the pages of 6.2.2.  (body) (date) opinion No. to pages 6.2.3.  (body) (date) opinion No. on the pages of 6.2.4.  (body) (date) opinion No. on the pages of 6.2.5.  (body) (date) opinion No. on the pages of a construction Developer 6.3. opinion no _____ to ____ pages (date) 6.4 on dūmkanāl and the ventilation channel of the technical condition of the ____ pages, Act No. (date)
7. The construction of the national control Office was hiring outside executives and professionals and found: 7.1. construction work carried out on the basis of the planning permission no _____ _____ _____ (date) issued by the national environmental service 7.2 construction started and completed on (date) to (date) 7.3. building or part thereof complies with the construction plan, developed by (name of the legal person, registration No., registration certificate No būvkomersant.) 7.4 changes and deviations from the agreed projects/no (delete as appropriate) allowed. Deviations agreed and marked in accordance with the procedure laid down in the technical documentation 8. Building technical economic indicators: construction: 8.1 8.1.1. floor (which carried out works/total design) ____ _____/_____ ____ 8.1.2. height _____ _____ _____ m 8.1.3. building area (new building) _____ _____ m2 8.1.4. the total area (which performed work/total design) ____ _____/_____ ____ m2 8.1.5.  būvtilpum (that works/total design) ____ _____/_____ ____ m3 8.1.6. construction structural design and decoration: No. p. k. Construction and decoration material Type 8.1.6.1. basics 8.1.6.2. vertical construction 8.1.6.3. 8.1.6.4 intermediate floors. roof construction 8.1.6.5. roofing 8.1.6.6. facade decoration 8.1.7. the degree of ugunsnoturīb ____ ____ ____ ____ ____ ____ ___ 8.1.8. the energy efficiency class ____ _____ ____ ____ ____ _____ 8.1.9. structures uses all or part of a specification: p. k. Usage description quantity 8.1.9.1.     8.1.9.2.8.1.9.3.    
8.1.10. engineering equipment (required mark): power supply: centralised 8.1.10.1. autonomous (wind water solar other) gas supply 8.1.10.2.: centralized local (the reservoir balloon) 8.1.10.3. water supply: centralized local (artesian wells in the block of open ūdensavot) external fire-fighting water supply water supply 8.1.10.4 internal fire. heating: Central, Central (boiler) 8.1.10.5. fuel: solid liquid gas electricity. 8.1.10.6 hot water supply: centralized local 8.1.10.7. sewage: Central, local technological 8.1.10.8 the individual rainwater treatment plant. : chemical biological mechanical ventilation: natural 8.1.10.9. forced 8.1.10.10. the lift: the other _____ _____ _____ _____ _____ _____ ____ ____ ____ 8.1.10.11. electronic communications networks: a phone, internet, other ___ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ 8.1.10.12 security system: fire protection systems for emergency notification of circumstances aizsargsignalizācij-8.2. external inženiertīkl: 8.2.1. inženiertīkl type (water, sewage, cable, etc.) _ _ _ _ _ _ _ _ _ _ _ _ _ 8.2.2. route length ____ ____ ___ ___ m 8.2.3. surface part ____ ____ ___ ___ m 8.2.4. underground part of ____ ____ ___ ___ m 8.2.5. inženiertīkl technical characteristics: No. p. k. Inženiertīkl way construction cross section (mm) material (m) 8.2.5.1.         8.2.5.2.8.2.5.3.        
8.3. Street (road transport): 8.3.1. Street (road transport) overall length ____ _____ m 8.3.2. total area, which made the job, _____ ____ suspended area m2 8.3.3. ___ ___ ___ m2, sidewalks area ____ _____ m2 of lawn area 8.3.4. ___ ___ ___ m2, the outlying area ____ _____ 8.3.5.50 m2 with lawn slopes media _____ ____ m2 8.3.6. Street (road transport) technical characteristics: No. p. k. Construction technical indicators (m) 8.3.6.1.     8.3.6.2.8.3.6.3.    
8.3.7. the package description: No. p. k. Building usage quantity (m2) 8.3.7.1.     8.3.7.2.8.3.7.3.    
8.4. environmental accessibility (if planning permission for certain accessibility requirements): area facilities, access roads, streets, pavements, walkways and pedestrian crossing for the chance to move from one level to another height of other requirements for the affected territory 9. Construction total cost (after the construction of the proof of the agent) is _____ _____ _____ _____ euro, including public law legal persons, policy instruments of the European Union or other foreign financial assistance funds-____ ____ ____ ____ ___ ___ Euro 10. Internal and external inženiertīkl and equipment tested and recognized as valid for operation. The findings added to this Act 11. Technological lines and equipment constructed, assembled, tuned, tried and accepted by the documents annexed to this Act 12. Outstanding works (territory greening, a fragment of the facade decoration) must be completed and the following time limits: No. p. k. The name of the unit of work completion date Quantity 12.1.         12.2.         12.3.        
13. after the adoption of the building or part thereof into _____ years atklājušo works the main operator of the construction defects will eliminate 14 at their own expense. The construction of State control, the Office proposes to recognise as valid (building or part thereof) For construction or 15 parts are brought (contested building permits) _____ _____ _____ _____ _____ _____ _____ _____ the court case number ____ ____ ____ ____ ____ ____ 16. Acceptance report drawn up in ___ ____ ____ ____ ____ ____ copies. Izpilddokumentācij is passed to the store ____ ____ ____ ____ ____ ____ ____ ____ ______.
      (position, name, surname)   (signature of the official veterinarian)
      (position, name, surname)   (signature of the official veterinarian)
      (position, name, surname)   (signature of the official veterinarian)
With the Act met: construction of the agent (name) (signature of the official veterinarian) (Date1) public works contractor (name) (signature of the official veterinarian) (Date1) notes. 1.1 document properties in the "signature" and "date" does not fill in, if an electronic document is drawn up according to the law on electronic document design. 2. the Provisions of paragraph 8.2. and 8.3. filled in according to the situation, if the structures are built at the external inženiertīkl and the street. 3. In the box extend, if necessary to reflect more information. 4. the premises or part of conservation, conversion or renovation necessary, point 8 of the Act to the extent that fills the building or part of the changes. Economy Minister Dana Reizniec-oak 11. Annex a Cabinet of 24 November 2015 regulations no 661 certificate about absence of construction (cognitive picking location) on (date) the cadastral designation (building name), (address) is demolished.
1. details of the demolished structure: 1.1. the owner of the building or, if not, the legal possessor and/or user (an individual's name, social security number, or the name of the legal person registration No.) 1.2. the structures Group (General provisions) 1.3. premises the main use (according to the classification of structures) 1.4. construction surface floor building dismantled the 1.5 inženiertīkl 2. News of the plot of land where the demolished building: land units 2.1 cadastral designation 2.2. land units address 2.3. owner of the land or, failing that, the legal possessor and/or user (an individual's name, social security number, or the name of the legal person , registration No.)
3. details of construction: construction Agent 3.1 (persons name, surname, personal code, place of residence or entity name, registration No., address, and phone number) 3.2 works carried out on the basis of the national environmental service (date) issued the construction permit no. 3.3. the surveyed object (date) 3.4 deferred construction (landscaping and improvement areas) must be completed and the following time limits: No. p. k. The name of the unit of work completion date Quantity 3.4.1.         3.4.2.         3.4.3.        
4. The certificate drawn up _____ _____ _____ _____ _____ _____ _____ copies. Izpilddokumentācij is passed to the store ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ construction national control Office of the designated officer (job title, first name, last name) (signature of the official veterinarian) notes. 1. the document property "signature" does not fill in, if an electronic document is drawn up according to the law on electronic document design. 2. Cognitive relative box expandable if necessary to reflect more information. Economy Minister Dana Reizniec-oak